Construction Manager Resume Samples

The Guide To Resume Tailoring

Guide the recruiter to the conclusion that you are the best candidate for the construction manager job. It’s actually very simple. Tailor your resume by picking relevant responsibilities from the examples below and then add your accomplishments. This way, you can position yourself in the best way to get hired.

Craft your perfect resume by picking job responsibilities written by professional recruiters

Pick from the thousands of curated job responsibilities used by the leading companies

Tailor your resume & cover letter with wording that best fits for each job you apply

Resume Builder

Create a Resume in Minutes with Professional Resume Templates

CHOOSE THE BEST TEMPLATE - Choose from 15 Leading Templates. No need to think about design details.

USE PRE-WRITTEN BULLET POINTS - Select from thousands of pre-written bullet points.

SAVE YOUR DOCUMENTS IN PDF FILES - Instantly download in PDF format or share a custom link.

Create a Resume in Minutes

M White

Mireya

White

616 Leila Burg

New York

+1 (555) 991 1905

616 Leila Burg

New York

Phone

p +1 (555) 991 1905

Experience Experience

Houston, TX

Construction Manager

Houston, TX

Collins and Sons

Houston, TX

Construction Manager

Applies technical and/or managerial expertise to improve effectiveness and provide guidance to employees in own area
Assist the Owner’s Project Manager in checking and approving the Status of Work Progress Instalments and contractors’ applications for payment
Assist project management in developing and implementing project procedures, working documents, standards, etc
General inspection of the workers and their performance, work plans, and safety
Conceptual development and budget management of projects and programs (route development, estimate costs, plan projects, schedule projects, and mapping)
Review performance against agreed objectives and take whatever action necessary to correct/improve the performance
Responsible for schedules and insures the workmanship of all work by inspecting and approving trade partner’s work

present

Phoenix, AZ

Construction Manager

Phoenix, AZ

Hamill and Sons

present

Phoenix, AZ

Construction Manager

present

Will also work closely with their assistants to verify the accuracy of any work that the Contractor’s subcontractors are performing on a cost plus basis
Manages Assistant Construction Managers; provides training and feedback to foster their growth and advancement
Work with the client and the applicant to identify projects that comply with the established categories of work for public assistance
Ensure all crew members and field supervision perform work in a safe manner and follow all established safe work practices and protocols
Reports to the Bid Manager and coordinates with the Design Manager, Estimation Manager and Commercial Manager of the Bid office
Monitors equipment performance and utilization; provides continuous improvement input and strategy development
Work with Architect to develop preliminary scope of work to establish a proposed budget

Education Education

Bachelor’s Degree in Engineering

Bowling Green State University

Bachelor’s Degree in Engineering

Skills Skills

Experienced in Engineering Activities, with good knowledge of Civil / Structural Steel deliverables along the project phases
Expert knowledge of building products, construction details and rules, regulations and quality standards
Strong collaboration skills and ability to lead a team of professionals
Solid engineering project management experiences, have good HSE knowledge and engineering design & construction coordination experience
Excellent written, communication and organizational skills and excellent oral, strong interpersonal and negotiation skills
Solid knowledge of quantifiable process improvements through structured innovation, continuous improvement methodologies such as lean
Sound knowledge of API, ASME, OSHA, and DOT codes and standards with an ability to apply that knowledge to pipeline projects
Ability to reinforce rules and recognising good performance i.e.. Health, quality and safety
Solid working knowledge of the Guide to the Project Management Body of Knowledge
Excellent trouble shooting skills and able to provide immediate solutions

Create a Resume in Minutes

15 Construction Manager resume templates

Read our complete resume writing guides

Construction Manager Resume Examples & Samples

Responsible for the overall administration and execution of assigned projects in a safe, profitable and timely manner
Responsible for coordination with internal planning departments to insure that approvals for land development are received within the project schedule guidelines
Responsible for governmental inspections and approvals through final certificate of occupancy
Perform and/or oversee construction document review and constructability reviews
Coordinate design team efforts to insure timely construction document package
Provide interface between facility construction efforts and other Project Team member
Provide interface between facility construction efforts and Park Operations, EH&S and Agencies
Responsible for overseeing construction estimating, bidding, contract negotiation, execution of the work and final close out phases of the projects assigned
Fully responsible for preparation and coordination of project work plans, schedules, estimates, and other planning documents included within the project scope, schedule, budget and quality objectives. This involves generation of the documents, soliciting and incorporating input from technical specialists, and ensuring a high-quality, complete document is generated that fully meets the projects expectations from a quality, regulatory, and technical standpoint
Integral to the planning and coordinating Project Logistics as it relates to Operations, Park Services, guest and employee traffic flow as well as adjacent ongoing construction activities
Supports approval of plans, schedules, and cost estimates through direct interaction with project manager
Coordinates and oversees construction staffing requirements and efforts of assigned personnel in carrying out project specific activities to ensure project objectives are met
Oversee Document Control process
Must have a good working understanding of California construction code requirements
Must be focused and able to manage large projects with strict adherence to budgets and deadlines in a fast-paced environment
Must be detail oriented with excellent organization and project management skills
Must have excellent written and oral communication skills
Must have strong leadership skills

Construction Manager Resume Examples & Samples

The Construction Manager will be the main field liaison between TWDC and the Contractor. Their primary responsibility will be monitoring close adherence to the project scope and schedule. This will include verifying and evaluating manpower for the Contractor’s subcontractors. They will keep close track of current and past production levels and use this to gauge progress and evaluate if current manpower levels are adequate to meet project goals. When problems arise they will work closely with the Project Manager and/or Contractor to assess the possible means to keep the project on schedule. This might include schedule logic revisions, increased manpower, increasing workhours, shiftwork, or possible combinations of these
Participate in both technical and non-technical document reviews, i.e. 30%, 60%, 90% design and shop drawings
Schedule the project in logical steps and budget time required to meet deadlines
Participate in the bid and award process
Provide direction to general contractor on behalf of the project manager
Coordinate the efforts of both outside contractors and internal trades as necessary
Inspect and review projects to monitor compliance with building and safety codes, and other regulations
Audit and assess contractor's performance on the contract
Investigate damage, accidents, or delays at construction sites, to ensure that proper procedures are being carried out
Integrate construction with Owner furnished items (both Owner and Contractor installed)
Meet operational standards by contributing construction information to strategic plans and reviews; implementing production, productivity, quality, and customer-service standards; resolving problems and identifying construction management system improvements
Responsible for the implementation, tracking of hours and materials for Field Authorizations, and Change Orders
Provide project strategies as well as a schedule for each project planning level (phase)
Monitor project construction and onsite procurement to conformity to contract terms and conditions, plans, and specifications
Must be knowledgeable of union rules and regulations
In addition to monitoring schedule he/she will also evaluate means and methods and try to ensure that the most economic and least disruptive approaches to the project are being utilized. They will work closely with TWDC’s operations personnel towards these goals. On most projects, it is anticipated that the Construction Manager will spend more than half the time in the field
Will also work closely with their assistants to verify the accuracy of any work that the Contractor’s subcontractors are performing on a cost plus basis
Will be heavily involved with the testing and commissioning of the fire alarm system and other life-safety systems as well as all final testing and inspections, including coordination with TWDC safety and operations
Will focus on trying to anticipate conflicts and discrepancies before they adversely affect the project. As the lead field representative he/she will be responsible for keeping a thorough daily log of activity being performed onsite. This will include subcontractors working onsite with location and manpower, major material deliveries, and equipment onsite, and will document any delays that may occur including ensuring that proactive solutions to problems are being pursued. This documentation could prove extremely valuable in the instance of claim defense or accident investigation
Mentor and guide project managers on best practices of construction management
7- 10 years experience as a Construction Management /Superintendent in commercial construction industry
Able to read and interpret construction documents
Familiar with and able to use Microsoft Office (Word, Excel, PowerPoint)
Experience working in a studio and/or corporate real estate environment
Familiarity with Tririga or other IWMS software

Construction Manager Resume Examples & Samples

Manage the entire construction process from design through construction and closeout, including all budgeting and scheduling, ensuring CapEx targets are achieved
Manage Design Review process to ensure complete scope of design and Crocs design guidelines and standards are being met
Ensure fixture inventories and vendor relations
Work with Architect to develop preliminary scope of work to establish a proposed budget
Responsible for maintaining all project documents, including construction documents and closeout documents in Expesite
Provide monthly cost reports to senior management, review all change orders and monitor all contractor and vendor payments
Negotiate contracts with GCs, consultants, and vendors
Solicit bids and award selection of GCs for projects
Manage review of potential remodel locations with real estate to determine existing conditions and implement strategy for remodel, scope, design, schedules, and budgets
Manage team of Project Managers/Store Openers
Adhere to business processes and drive improvement
Coordinate with various internal functions, including Facilities, Finance, Visual Merchandising and Marketing, Global Design, and Operations
3-5 years’ experience in construction, preferably in retail
Experience in all aspects of base building construction preferred
Knowledge of all construction trades, understanding of cost of construction by CSI categories/specifications
Ability to manage budgets
In depth knowledge of current construction methods, standards and procedures
Excellent computer skills including Microsoft Products – Excel, Word, Outlook
Knowledge of Expesite project management software
Proven ability in managing outside consultants including building relationships with general contractors, vendors, senior management, etc
Ability to multi-task and work on multiple projects in a fast-paced work environment
Ability to work within stringent time-frames
Travel is required 25%-50% of time

Construction Manager Resume Examples & Samples

Trade qualification
Experience in Joinery, Plastering, Dry Lining
Excellent managerial qualities
8-10 Years working in a similar role for a reputable company
Enthusiastic personality with the ability to integrate with a diverse work force
Middle East experience is advantageous but not essential

Construction Manager Resume Examples & Samples

Site Management
Health & Safety Regulations
Hiring of Construction staff
Budget/ Cost Control
Coordinate, control and monitor all subcontractors on site
Start new build projects from groundwork and manage through to completion overseeing stringent quality control of both external and internal finishes
Plan, organise and if necessary, take corrective action on individual projects
Control multiple construction projects
Collating and issuing tenders to a varied range of subcontractors and suppliers
Review of tenders and quotations - acknowledging costs and scope of works for the project
Raising subcontract and purchase payments
Appointment of contract orders
Extensive knowledge of current building legislation and regulations
Up to date with latest technical requirements for house build construction
Have practical construction knowledge and be able to work from drawings
Be familiar and able to work to programmes
Experience in making decisions and ability to prioritise tasks

Construction Manager Resume Examples & Samples

Supervises staff by providing assistance, guidance, and problem resolution, assigning work and evaluating performance. Acts as the Lead on the total Serviceability Process. Supports all company EEO/AA objectives
Assist the Sr. Manager of Engineering and Construction in budget preparation by providing current and historical data and recommendations
Produces various reports detailing activity, compliance to standards and projects of future activity
Supports Construction Managers and teams by providing assistance and guidance in problem resolution, and serviceability processes and evaluating performance
Supports and oversees the Installation Quality Assurance, Locate and Damage Prevention Departments
Interacts with Utilities, DOT, and governmental authorities to assure good working relationships, and that all required permits are applied for and granted prior to any construction
Set and continually evaluated priorities and adjusts work schedules of subordinates to ensure completion of department task within the required time lines
Interacts with other departments to achieve department and company objectives
Prepares, submits and manages capital and operation budgets as well as provides material management analysis and support for the Engineering and Construction Managers, Install QA and Locate Supervisors and team members

Construction Manager Resume Examples & Samples

To Project Manage a portfolio of luxury store fit out projects across Emerging Markets Regions, ensuring they are within programme, budget and design tolerances
To develop and establish brief of project objectives and maintain stakeholder communication highlighting strategic and policy issues for the Development Team
The preparation and updating of overall construction strategies, programmes, schedules and other documentation to monitor and track objectives
Support the Real-Estate team in all aspects necessary to secure a strong lease for Burberry
Manage the Contractor tender process and the activities of the Development Team, the general contractor, specialist contractors and suppliers
Define and maintain a project cost plan covering all aspects of the planed CAPEX
Analyse each Works Package contract and identify the key interfaces critical path and milestones
Advise upon all areas of risk to the Works and risk management
To carry out inspections both on and off-site of the Works by the General Contractor and the specialist contractors and suppliers appointed directly and effectively communicate to the business on all matters relating to progress
Monitor and verify logistics plans for the Works provided by the general contractor and the specialist contractors and suppliers
Prepare organisational plans and structures and define responsibilities and reporting relationships
Advise on the strategy for procurement of all construction packages and purchase orders for works required to complete the project and manage the orderly handover of the Site to the business ensuring all administration is complete and up to date

Construction Manager Resume Examples & Samples

To Project Manage a portfolio of fast track fit out projects across EMEIA, ensuring they are within programme, budget and design tolerances
.Follow the Gateway process and issue close out schedules, leading up to completion. Snagging lists issued in a timely manner and followed up with contractors to a high standard. Issuing of the complete O+M manual in our standard format, within the agreed timescales
Growth in the role to manage renovations and major projects once they have gained experience in the role

Construction Manager Resume Examples & Samples

Provide on-site management of construction project activities ensuring coordination of contractors, vendors and various Bank departments and timely completion to meet end user needs; meet with end users as required. Resolve issues that arise during the project
Consult with end users to plan construction project. Develop detailed program requirements for personnel and equipment to be used, as well as efficient space plans, and design criteria
Provide cost estimates and designs for review and discussion with end users. Serve as liaison with architects and engineers to review designs
Purchase furniture and equipment required for approved construction projects
Prepare preliminary drawings for submission to Space Planning or architect for further development
Oversee work schedule development and coordination of activities through project completion
Supervise and coordinate end user move to new location to ensure a smooth transition to the new facilities
Review all related construction and space planning invoices, ensuring work has been properly completed and invoice agrees with budget
Responsible for related administrative activities supporting assigned construction projects including invoice processing, payment authorization, attending board meetings to secure appropriate approvals, project reporting and CAD (Computer-Aided Design) updates
Promote an environment that supports diversity and reflects the M&T Bank brand
Complete other related duties as assigned
Bachelor’s degree or related field and a minimum of 3 years’ proven construction-related and/or corporate facilities experience and minimum of 2 years’ prior project management experience, OR in lieu of a degree, a combined minimum of 7 years’ higher education and/or work experience, including a minimum of 3 years’ proven construction-related and/or corporate facilities experience, with a minimum of 2 years’ prior project management experience
Valid state driver’s license
Ability to read and understand architectural and engineering drawings
General knowledge of AutoCAD, basic drafting and specification knowledge
Proficiency with personal computers as well as pertinent software packages
Proven verbal and written communication skills with ability to use tact and diplomacy with all levels of personnel
Significant travel required; frequent in-region travel, occasional travel out of home region, including overnight travel
Availability to periodically work nights and weekends to complete project work and relocations

Construction Manager Resume Examples & Samples

Contractor Management
Mechanical or Civil background in construction management
Thorough understanding of Health and Safety

Construction Manager Resume Examples & Samples

Supports Store Development, Licensing and Operations goals by participating and contributing in planning and strategy meetings for the markets. Plans and manages construction processes and practices to ensure that programs are aligned with company business goals and objectives
Building long-term account value with executive level relationships within development departments of key partners and companies
Developing action plans in response to customer requests for store alterations and special projects. Recommending renovations of existing locations to meet customer requests and brand standards
Manages and monitors project schedules within budget guidelines, progress and costs to ensure projects are completed on time and effectively
Consolidates, communicates and manages all issues and risks affecting the project. Communicates project status to project participants and stakeholders accurately and on time
Supports the construction phase of the development process with licensees. Monitors vendors performance during construction build-out phase. Oversees ordering and tracking of materials and equipment. Visits job regularly to perform due diligence and monitor quality
Follows the permitting and approval phase of the development process and ensures all proper approvals have been received from all functions to proceed with construction phase
Providing site selection assistance to business partners and licensees, site validation and support to the sales team during the sales cycle of the development process. Training teams in the development process, real estate and site selection
Visiting new stores to insure compliance with all applicable building and health codes and regulation; Starbucks standards
Develops and manages budgets consistent with timeline requirements for new store development or renovation projects. Develops scope of work consistent with licensee and operation needs and budget allowances
Supports licensee during bidding process and contract negotiations
Oversees and maintains relationships with external licensees, professionals and consultants. Oversees vendor performance during construction phase through site visits and report review. Maintains relationships with statutory authorities e.g. building control, town & country planners etc to ensure seamless store openings
Provides coaching, direction and leadership support to team members and licensees in order to achieve partner, business and customer results
Bidding and negotiations
Budgeting and planning
Construction management
Progressive experience managing a construction team in a multi-unit retail or restaurant environment
Project management with experience managing multiple projects
Financial analysis
Minimum of 5 years of solid construction experience
Relevant Bachelor degree, construction/building services or engineering desired
Membership of CIOB or RICS desired

Construction Manager Resume Examples & Samples

Responsible for the overall administration and execution of assigned project in a safe, profitable and timely manner
Fully responsible for preparation of project work plans, schedules, estimates, and other planning documents included within the project scope, schedule, budget and quality objectives. This involves generation of the documents, soliciting and incorporating input from technical specialists, and ensuring a high-quality, complete document is generated that fully meets the projects expectations from a quality, regulatory, and technical standpoint
Supports approval of plans, schedules, and cost estimates through direct interaction with project director
Minimum qualifications include either an engineering or construction management degree or the equivalent of 15 years direct construction experience in a related field including leadership and supervisory roles
Proficiency in MS Office suite of applications
Ability to achieve results through flawless execution of strategies & objectives
Ability to effectively communicate across all lines of business, and with all levels of management
Excellent verbal and written communication, interpersonal, organizational & multi-tasking skills
Strong organizational, planning, delegation & mentoring skills
Ability to deal well with ambiguity and constant change
Strong passion for delivering the highest quality of guest experience

Construction Manager Resume Examples & Samples

Work with or assist the estimating group to establish preliminary construction cost (conceptual estimate), during the design/development process to achieve a target budget for approval by senior management
Maintain a Job Cost Analysis report (JCA) on a monthly basis
Accurately prepare and ensure timely submission of required documents for necessary building permits and occupancy permits in accordance with customer’s schedule objectives
Manage the construction process by conducting regular job site meetings with subcontractors, owner representatives, architects, engineers, consultants, and other project personnel. The primary objective of the meetings is to provide direction to the process, set priorities for action and decision making, resolve challenges between the parties, and manage the team objectives consistent with the vision of the customer
Work with the Construction Superintendent to monitor on-site safety regulations and procedures to ensure compliance with all regulatory agencies
Ensure the adherence to Jones Lang LaSalle insurance requirements and that all parties have necessary certificates in place prior to commencement of their respective work
Responsible for adhering to Jones Lang LaSalle’s Authorization Limits regarding financial matters and procedures
The timely close-out of projects including completion of punch list, final Application for Payment, and submission of all close-out documents (i.e.. As-builts, manuals, certificate of occupancy, final application for payment, recognition of savings or loss, etc.)
Manage, oversee, and provide training and be a mentor to Assistant Construction Managers. Perform performance evaluation if so designated
Outstanding interpersonal skills, client service attitude, attention to detail, and the ability to communicate effectively with a diverse group of individuals
5+ years’ experience in commercial construction

Construction Manager Resume Examples & Samples

Obtain the necessary permits on construction projects
Manage contracts and issuance of work orders
Manage daily job progress
Assist in development and monitoring of construction budgets
Review architectural designs and plans complying with local, state and national building codes Provide final review and approval of all projects
Manage quality control processes
Manage customer and vendor relationships
Managing 300 closings a year
Minimum of five years’ experience
Minimum of three years at Field Manager level
Construction Manager or Field Manager roles Construction experience

Construction Manager Resume Examples & Samples

Initiates and monitors processes for expenditures and ensures budgets are met
Maintains an invoice verification program on all contractor projects
Works with Marketing and Commercial Development to ensure budgeted subscribers are built, activated, and/or upgraded, as needed
Generally requires 6-9 years related experience

Construction Manager Resume Examples & Samples

1 Project Integration Management
Give Support to Civil Project Strategy development and updating
Give Support to Civil Change management
2 Project Scope Management
Takes ownership on Civil Turnover Packages (CTO) definition
3 Project Time Management
Take Ownership on elaboration and necessary revising of the Civil Site Time Schedule (STS) based on design construction sequence
Take Ownership on follow-up and revising of the Civil Specialized Structure Schedule per contract
Manage on site progress monitoring and assessment of time to complete up to CTO
4 Project Cost Management
Give Support to Root Cause analysis of all no budgeted costs to Project Manager Civil
5 Project Quality Management
Take Ownership on civil quality control inspection process (CTO,...)
Take Ownership on checking of compliance of construction with scope and quality requirements
Take Ownership on technical execution expertise for a specific subject (Soil condition/improvement, concrete works, steel structure, finishing works, road and landscaping, specialized structures)
Take Ownership on civil punch list item up to the PAC
6 Project HR Management
Give Support to personnel planning
Take Ownership on setting and reviewing tasks & objectives for his subordinates
7 Project Communication Management
Give Support to definition of the Civil Communication plan (information flow and document distribution)
Give Support to establishing the Project Progress Reporting
Give Support to Design Progress Reporting
Take Ownership on establishing the Execution Progress Reporting
Give Support to Project Meetings (Kick Off, Team, Monthly etc…)
Give Support to Design Meetings (Kick Off, Weekly, Monthly internal and external)
Take Ownership on Execution Meetings (Kick Off, Weekly, Monthly internal and external)
8
9
8 Project Risk Management
Give Support to elaborating Risk Assessment and Rating
Give Support to Risk Mitigation Plan and follow-up of the same
9 Project Procurement Management
Give Support to preparation of technical conditions of subcontracts for all extra works
Give Support to evaluation, negotiation and award recommendation of civil subcontracts
Objectives, targets and performance measurements are defined on yearly employee’s appraisal and Project Targets are set by the Head of Civil Project Management / Operation
Civil program and Civil Turn Over reliability of related Project
Quality of Civil works of related Project
EHS requirements within Civil Works of related Project
Customer satisfaction
3 Specific Functional/Technical authority (besides DoA)
Apply organizational structure of civil superintendents and supervisors team
Manage civil superintendents and supervisors
Represent civil Construction with ownership related to EHS, quality, technical and time
Contribution, take ownership and support related projects to comply with cost, time, quality, EHS and Customer satisfaction targets
Profile
1 Education & Trainings
Undertake any other duty and responsibility as may be required by the Line Manager
Promote and champion “We Put Quality First”, EHS “All together”, “Zero Deviation Plan” d2e and any other plans implemented by Alstom
Promote the interests and image of the company at all times
Behave according to ALSTOM Code of Ethics and Values
Willing to work anywhere in multicultural team

Construction Manager Resume Examples & Samples

Leadership/team facilitation skills
Strong understanding of facility systems and equipment
Ability to develop, read and interpret blueprints
Experience as a project estimator

Construction Manager Resume Examples & Samples

Sets priorities to ensure task completion; coordinates work activities
Uses operational and supervisory expertise to solve problems
Directs contractors in such a way to support business objectives
Works within budget to meet operational goals
Resolves routine problems using defined processes and own experience
Coordinates resources to meet short-term objectives
Explains difficult issues and obtains agreement as needed
Minimum 10+ years of industrial experience working as Construction Manager
Has in-depth knowledge of work processes and tools
Has excellent project controls understanding

Construction Manager Resume Examples & Samples

Conduct field meetings with client and general contractor in the field, as required
10+ years of bridge and heavy highway construction with NICET IV or PE
5+ years on Transportation, Bridge or Highway construction projects
Experience working with public agencies (PennDOT / PA Turnpike preferred)

Construction Manager Resume Examples & Samples

Provide oversight of construction related activities and supporting the PM, as needed
Assists in developing solutions for unforeseen site conditions
Review contract submittals
Familiarity with Design Build contracts
Demonstrated knowledge of and ability to use Microsoft Office Products: Word, Excel, and PowerPoint software

Construction Manager Resume Examples & Samples

Lead and direct team of site inspectors performing statutory site supervision. Such supervision (pol. inspektor nadzoru) on behalf of the Investor is required by law in Poland and it has to cover construction, sanitary and electrical installations (functions performed by supervision inspector). The scope of investor’s supervision duties performed by the General Contractor is defined by law and includes the following most important items
Regular on-site inspections to control compliance of works with the building permit
Regular monitoring of the GC daily construction records and entries in the construction book
Verification of site book kept by GC
Verification of material certificates
Checking works performed by GC and subcontractors
Active participation in inspections of the facility
Regular check the GC is preparing, collecting and submitting all necessary technical performance documents (preparation of functional diagram, work organization diagram, concealed work acts, test acts, logbooks, quality certificates, passports, etc.) as per the contract and Laws of Poland requirements
Verification of as-built documentation submitted by the general contractor (post completion documentation)
Performs role of statutory site supervision (preferably in building and civil trade)
Oversee/control construction through strong management of his subordinates to ensure project is delivered in accordance with design, budget, schedule, quality and required SHE standards. Includes interfacing with client representatives, general contractor, nominated subcontractors, designers/consultants and tenants
Plan, organize and ensure the resources are in place for inspectors and SHE field position for various stages of the project
Check the GC regularly updates the master programme to show overall progress to date, time to completion and corrective action when necessary
Liaise with the GC to check their programmes show required detailed schedule of activities including submission of samples and installation of mockups; the production of working drawings; the manufacture and transport of components; together with the site construction works themselves and timescales for testing and commissioning where appropriate
Supporting PM in administration of the design approval process
Quality - Monitors GC Quality Control Plan and responsible for management of corrections with the GC
Review, amend and approve GC monthly progress payment reports. Vetting GC monthly reports
Interface with public and statutory/regulatory officials as required
Interface with the General Contractor (GC) and his safety managers to check that standard safety procedures are being adopted and project requirements are being satisfied and the sanitary and security rules as per the laws of Poland and conditions of contract are being adhered to
Support project Manager in establishing effective communication routs for the project
Support production of the project monthly reports and other administrative documents to effectively manage the contract administration process
Chairing regular GC progress meetings and ad hoc meetings as required
Leading testing and commissioning process. Taking a lead in obtaining of statutory approval including Operation permit
Ensuring a strong team ethos and spirit among the project team focused on successful delivery and solution rather than problem focused
Supports project manager in strategic monitoring of the project and risk analysis ensuring mitigation measures to plan and anticipate foreseeable issues
Ensure all company, client and project policies/procedures are adhered to
Provide advice, guidance, mentoring and direction to subordinates and other junior personnel toward the achievement of their personal development goals
Effective collaboration with the client and their team
Ensuring all the AECOM project processes are strictly adhered to including the variations, RFI’s, contractor invoice and payment process, etc
Accommodate additional responsibilities as assumed through personal initiative or assigned by higher authority
Educational construction (architect, engineer, mechanical, electrical) degree, plus extensive experience in project management of flag retail schemes in Poland (shopping centres)
Statutory license for supervision of construction works
Advance knowledge of the retail market in Poland, risk management and field operations required
Excellent organizational, leadership, communication and analytical skills are necessities
Demonstrated mastery in the skills of project construction management
Experience in management of teams of inspectors
Experience in tenants co-ordination at large retail scheme will be an advantage
Knowledge of Polish statutory construction regulations and permitting process
Fluency in English (meetings, correspondence and reporting to Client is in English)
Driving License cat. B

Construction Manager Resume Examples & Samples

Form teams and proactively coordinate numerous items on a schedule
Review and evaluate the project schedule
Read and interpret contract requirements and read engineering drawings
Collect, analyze and compare work performance with contract requirements and to make recommendations to for any performance issues
Support the Pentagon Building Management Office (PBMO) in the project management of maintenance and repair building infrastructure projects
Support other efforts, as assigned to include organizational assessment, strategic planning, mission analysis, and project development services
Strategic planning for technology programs and activities involves the definition, interpretation, and development of high-level organizational technical engineering performance requirements for the successful execution of tasks, projects and programs; and the development and implementation of processes in support of the organizational mission at the macro or micro scales

Construction Manager Resume Examples & Samples

Buyer’s Technical Representative Training (BTR)
OSHA 40 hr Hazardous Waste Worker
OSHA Hazardous Waste Worker for Supervisors
Radiation Worker II

Construction Manager Resume Examples & Samples

The successful delivery of the project in compliance with the contract documents and document all changes to the contract
The daily contact with the client and manage the sub-consultants and other Arcadis staff. Prepare meeting minutes, maintain Submittal, RFI, Correspondence , Change Order and Pending Change Order logs, change order negotiations with the contractor
Assist with Monthly Invoice, preparing and administering sub-consultant agreements
Minimum years of experience: 5 Years
Must have Airfield experience and understand QC Testing and managing sub-contracts
Education required: Bachelors
Registrations/Certifications required: EIT / PE
Special considerations, specific technical experience, skills, etc
This position does require travel. Travel amount is negligible
A valid driver’s license and clean driving record is required for this position
This position could manage others
Education preferred: Bachelors of Science Engineering
Project Manager or Engineer for construction project of $6M

Construction Manager Resume Examples & Samples

Analyze monthly construction contractor CPM schedule updates; develop progress payments based on schedule updates; assist with recovery schedules
Strong communication skills, both oral and written. Independently write reports and correspondence
Work collaboratively with the contractor (s), local government (s), and other agencies having jurisdiction and Owner to solve project challenges representing the Owner's best interest
Solve complex challenges relating to project schedule and budget as an effective member of the project Team (Owner, ARCADIS, and Contractors)
Observe and monitor contractor team to ensure that the project is being constructed in accordance with the approved plan and specifications and that critical project milestone will be met
Ability to track and manage General Contractors and subcontractors
Supervise inspection personnel and on-site construction for conformance with contract requirements
Highly organized in work habits to consistently and accurately support the team and manage a variety of critical tasks
Professional Engineer licensed in NY and/or NJ
Project and/or Construction Management experience required to include rail construction – track, right-or-way improvements, yards, facilities, stations, tunnels, power systems and security systems
Experience required in constructability review, design completeness review, construction, commissioning and validation
Experience required in CPM scheduling including baseline review, recovery schedules, and updates
Experience required in the full suite of MS Office products
Certifications desired, but not required, include: CCM, PMP, CCE, CCC, or PSP

Construction Manager Resume Examples & Samples

Serves as single-point of contact, between the Lead Construction Manager and construction
Reports project status and performance data as required to management
Identify and assesses improvement opportunities, which will add value
2 years with a degree or 3 years at Superintendent level; Bachelor’s degree in construction, engineering or heavy industrial experience preferred, or relevant experience
3+ years of relevant (Wireless and OSP/ISP telecommunication industry) Construction
Knowledge and experience in wireless construction and telecommunication technology
Responsible for coordination of the construction on the project

Construction Manager Resume Examples & Samples

Manages and coordinates all on-site subcontractor activities for compliance with the CPM schedule and monitors and enforces compliance with subcontract requirements; Implements the Project Construction Execution Plan
Monitors and reports on construction productivity and schedule performance (including trends) to the Project Field Manager and Field Project Controls Manager. Takes actions necessary to meet project budget and schedule requirements
Directs the establishment and implementation of subcontractor schedule recovery plans as required
Conducts weekly coordination meeting with subcontractors
Monitors all extra work authorization requests, backcharges, and supplier and subcontractor progress/final payment requests for acceptance and is responsible for subordinates providing the timely tracking information to Project Controls to support the change management system
Monitors and approve all CIR replies to the subcontractors
Resolves safety and quality issues with the safety and quality managers. Further disputes are then deferred to the Project Field Manager
Has the ability to stand in for the Project Field Manager in his absence
Understands the major commercial and deliverable terms of the construction subcontracts and manages within these terms
8+ years of Water/Wastewater experience in a Construction Management or Resident Engineering role

Construction Manager Resume Examples & Samples

Manages and coordinates all on-site construction activities for compliance with the schedule and monitors and enforces compliance with contract requirements. Directs field staff in the daily, weekly planning process
Monitors and reports on construction productivity and schedule performance (including trends) to the Lead Construction Manager. Takes actions necessary to meet project budget and schedule requirements
Coordinates the Construction Completion Walkdowns and the complete hand over of the site
Assists Lead Construction Manager with client interface and relations
Coordinates with Material Manager to review all procured materials for acceptance
Conducts weekly coordination meeting with field staff & subcontractors
Reports weekly schedule and commodity installation status to the Lead Construction Manager
2 years experience with a degree or 3 years + experience at a Superintendent level or above

Construction Manager Resume Examples & Samples

Ensure that HSE matters are given due consideration in project planning
Take the lead role in constructability reviews during design / model reviews
Supervise, advise and guide the construction discipline personnel to ensure that their work is of the required quality
Highlight issues that may arise in priorities, workload, competency, etc
Support the Planning Engineers in developing the construction plan for each project to achieve the specified project / construction specific deliverables
Control over manpower and material resources in order to execute the project within budget, schedule, quality and HSE requirements
Focal point for the site related works and therefore shall ensure effective communication with and involvement of all construction personnel on each construction project
Bachelor's Degree
Minimum of 5 years of experience in relevant downstream oil and gas Industry

Construction Manager Resume Examples & Samples

Min. 15-20 years’ experience in the design and construction of chemical, petrochemical, oil & gas, refinery facilities
Having high regard for Environmental Health and Safety culture and practice
Ability to manage multi discipline design and construction teams
Ability to communicate in an articulate manner with clients, consultants, and subcontractors
Willingness to travel, if required
Highly motivated, well organized, resourceful, and proactive
Ability to promote an open and informal communication environment that aims at growing mutual trust and teamwork

Construction Manager Resume Examples & Samples

B.Sc. or equivalent degree in Engineering from an accredited university with minimum 20 - 25 years relevant experience in the oil and gas industry including 15 years of outstanding construction management experience
Must have a proven ability to manage the team of engineers of various specialists and also multi-national team
Prior experience on working in middle east offshore/ onshore construction is mandatory

Construction Manager Resume Examples & Samples

Ensure that key KNPC relationships are maintained at all levels within the project
Create and sustain a good team spirit within the Amec Foster Wheeler project team and KNPC
Create and sustain a good team spirit with assigned geotechnical & marine, tankage and commissioning PMC support subcontractors
Provide leadership, guidance and direction concerning all facets of construction, completions and their delivery
Interface with KNPC, PMC subcontractors and the EPC Contractor for formal and informal reviews on construction and safety related matters
Provide construction and safety guidance and direction as may be required
Monitor and review construction related documentation originated by the EPC Contractor
Review and monitor the EPC Contractor’s and their Subcontractor’s construction activities including resourcing thereof
Participate in key KNPC reviews and meetings as required
Participate in Monthly Progress reviews with the EPC Contractor
Participate in monthly KNPC and Amec Foster Wheeler project progress reports and presentations
Coordinate and resolve filed construction queries interfacing with engineering and completions
Monitor, appraise and report to KNPC on quality and safety construction performed by the EPC Contractor and their Subcontractors / Vendors
Provide HSSE leadership and awareness by ensuring that all Amec Foster Wheeler and KNPC requirements are implemented and followed including safe delivery of the work
Ensure HSSE system compliance and conduct periodic reviews
Ensure quality assurance system compliance and conduct periodic reviews
Conduct periodic site HSSE visits, reviews and audits
Recruit supporting and lead personnel as required for the PMC positions
Bachelor of Science / Engineering Degree
Minimum 15 years post graduate industrial experience
Minimum 10 years’ experience in refinery and / or petrochemical industries
Functional management, leadership and teambuilding skills
Strong HSE awareness and commitment
Prior PMC experience an asset
Prior Middle East experience an asset

Construction Manager Resume Examples & Samples

Managing / supporting Resident Construction Manager to manage overall construction project site technically and administratively in accordance with the contractual requirements between the Client & the Company and in alignment with the AmecFW HSE and Quality Plans, Procedures, Work Practices
Managing Client and Contractors
Ensure during the construction phase, hazard identification is achieved by a combination of HAZCON reviews, Constructability reviews, Contractors' Method Statements and on-site inspections, as applicable
To review drawings and documents
Ensure that the AmecFWIPL Health, Safety, Environment, Security (HSES) and quality policy is understood and implemented by all concerned including construction contractors, vendors and visitors at site
Ensure that the project achieves its objectives in respect of HSES, quality, cost and schedule
Minimum 20 years of experience in reputed EPC organisation in the capacity of a Construction Manager or RCM for atleast 5 years managing a project value of ~ INR 700 crores in Oil & Gas / Refinery / Petrochemical / Chemical Sectors (Essential)
Must have worked in the capacity of Construction Manager in at least one LNG Project and two EPC Projects in Refinery & Petrochemicals in the role of PMC / EPCM / EPC Contractor in a globally reputed company
Must have through knowledge of Project and Construction Management, Coordination, Work Sequencing, Interfaces and Contract Administration of large complex projects
Must have strong knowledge of HSE and QA / QC
Should have strong communication and leadership skills
Should be conversant with construction related central & local legislations and industrial relations

Construction Manager Resume Examples & Samples

10+ years of experience in construction for industrial markets
Knowledge of Work Breakdown Structures necessary
Ability to read construction drawings for data center and industrial projects
Associate's Degree in Construction or related field
Certified Construction Manager (CCM) a plus

Construction Manager Resume Examples & Samples

Set and manage productivity and performance expectations for direct reports
Maintain schedule of installers and track hours assigned to projects
Provide accurate project status updates during WIP meetings
May help interview and/or evaluate employees and apprentices

Construction Manager Resume Examples & Samples

Provide construction management oversight, including client relationships, managing scope, schedule, budget, deliverables and change orders for various construction and rehabilitation projects
Monitor construction progress and quality
Facilitate and/or coordinate resolutions to questions or other construction issues
Management of construction management staff
Coordination and issue resolution with design firms
Minimum 10 years of progressive responsible experience on a Construction Management team
Performed project management or construction management on projects of $10 million or larger
Strong proficiency with Microsoft Office (Word & Excel)
Interacts well in a dynamic, office team environment
NYS PE license preferred
Residential and/or vertical construction experience, including single-family, multi-family, high-rise residential or commercial buildings preferred
Certified CCM or PMP
Primavera P6 and Contract Manager proficiency

Construction Manager Resume Examples & Samples

Responsible for gross revenue of <$1M
Responsible for coordinating between Contractor and Architect in the timely resolution of technical field issues
Coordinate with Architects and Engineers for timely and accurate responses to requests for information
Develop strategies with the contractor to create submittal packages that conform to schedule requirements
Serve as technical liaison with client on project efforts
Provide cost control on projects and quality control within discipline
Ensure completeness and accuracy of design team work. Usually involves diversified work within general procedures, requiring frequent judgment and initiative
Responsible for the hiring, supervision, development, evaluation, and termination of staff members, as well as establishing and approving budgets for the group
Will occasionally be required to lift up to 50 pounds
Bachelor’s degree in Architecture, Engineering or Construction Management plus 8 years experience in project/construction management required
Basic computer knowledge and skills including SiteManager, Excel, Sharepoint and Word preferred
ACI Concrete Strength testing and TxAPA Level 1 preferred
Must possess a current, valid driver’s license

Construction Manager Resume Examples & Samples

Lead major construction projects on behalf of EPC as well as PMC contractor capacity
Must be familiar with the latest HSE standards, construction methods, and project management techniques, and have the leadership qualities in these areas
Coordinates contract packages, constructability reviews, site plan management and tracking and managing construction progress
Able to use previous experience in site job planning in terms of work fronts and materials requirements, and the scheduling of materials shipping so that the 500 strong contractor site team will be productive
Good experience in buildings completion
Bachelor or equivalent degree in Civil or Mechanical Engineering from an accredited university, preferable
Minimum of 15 years relevant experience in the building industry construction works; experience in the Oil & Gas industry is preferable
Must have been in Contractor or Consultant organization for at least 5 years in a similar position
Candidate must have extensive expertise in construction management of major EPC projects
Candidate must have managed at least three major construction projects during the last ten years

Construction Manager Resume Examples & Samples

Review and make recommendations on construction methodology and procedures including method statements, risk assessments, construction execution plans, constructability procedures, transport logistics and rigging plans
Establish and promote good working relations with the project staff, the Client and the EPC Contractor
Review PMC manhour estimates and manning mobilization plans and organisation charts
Support site surveys and the supervision of subcontractors for geotechnical, topographical and laser surveys on site
Attend plot plan and model reviews
Establish, manage and lead a PMC construction team to oversee all aspects of the work on site. The team will consist of HSE Management, Construction Engineering, Discipline Superintendents, Materials Management, QA Manager with inspectors and Completions Management
Ensure that the EPC Contractor implements the standards of international construction and the project procedures relating to construction. Above all other considerations the Construction Manager must be able to demonstrate a sincere adherence to the furtherance of HSE improvements in all activities
Contribute to an analysis of EPC subcontract strategy and division of work
Understand the EPC Contractor’s proposed construction schedule in detail, ensuring that it is realistic, and then drive the Contractor to deliver to that plan
Oversee mechanical completion and try to ensure a smooth turnover of the plant
Monitor closely the construction quality to ensure compliance with functional and construction specifications
Report to the Client on the adequacy of the site supervisor staff employed by the EPC Contractor
Co-ordinate the demobilization of contractors’ temporary site facilities and their removal from site
B.S. or equivalent degree in Mechanical Engineering from an accredited university with minimum fifteen (15+) plus years relevant experience in the oil & gas or petrochemical industry including at least ten (10) years of construction management experience for major projects
Must have familiarity with latest construction methods, modern project management techniques, and environmental engineering aspects
Requires specific knowledge in coordinating contract packages, constructability review, Site Plan management and tracking construction progress
Good understanding of the safety requirements applicable to large construction sites and in particular working in areas close to existing operations involving hydrocarbons and constraints resulting from simultaneous operations (SIMOPS)
Experience in ARAMCO Projects or SADARA Ex-employee is highly preferred

Construction Manager Resume Examples & Samples

Promote HSE awareness and ensure that all KOC / Amec Foster Wheeler HSE requirements are implemented and adhered to
Provide effective and practical construction input into study, FEED, and contract action phases of projects to ensure constructability aspects of project execution are adequately considered via the construction team
Ensure that construction hazards and risks are fully considered by designers and contractors, and that the appropriate mitigation actions are implemented during the project execution phase
Coordinate with all project stakeholders, especially within KOC, to facilitate the project execution with minimum disruption and hazards to both ongoing operations and the construction Contractor via the PMC Construction team
Ensure that the PMC construction team maintains efficient and effective communications between the Contractor and PMC, ensuring that all reporting requirements are met
Provide notification of any potential commercial risk or opportunity to the Project Manager for further action
Develop close working relationships between all assigned construction team members and the HSEQ team to provide a consistent approach and effective resolution of issues
Encourage the same degree of cooperation within the Contractor organization
Develop a good team spirit within assigned PMC personnel and encourage team working with the Contractor and other KOC groups
Ensure that construction team are maintaining the quality at an acceptable level, including all required records and tests; thus ensuring that pre-commissioning, commissioning and handover are achieved
Minimum B.Sc. Engineering or equivalent
Minimum twenty years post graduate experience
Minimum eight years experience in the oil & gas, refining and petrochemical industries
Minimum five years experience in the designation

Construction Manager Resume Examples & Samples

Experience with healthcare facility design
Ability to provide design reviews, including Joint Commission and other code review and compliance
Ability to review construction documents and coordinate with stakeholders, federal agencies, and contractors

Construction Manager Resume Examples & Samples

Provide off-site support (from home / Collinsville, IL office) of on-site activities at multiple locations concurrently
Develop Work Plans and Health and Safety Plans to support project and contract objectives
Serve in on-site role when needed as Site Construction / Health and Safety Manager for short duration projects (typically less than 30 days)
Maintains effective communications with client, subcontractors and Tetra Tech’s Project Manager
Implements plans and monitors work activities to ensure project execution supports compliance internal and external timelines and objectives
Schedule and conducts on-site meetings with the client and subcontractors as required; Liaises with client and prevailing government agency representatives as required
Resolves operational, customer, contractor or technical problems that impact the effectiveness of the project using defined processes
Maintains, project drawings and other project related documentation using MS Access or equivalent database
Experience depicting management of on-site construction activities, construction quality control, construction safety, and systems inspection activities affiliated with U.S. military fueling systems is highly desirable
Ability to read and interpret construction project drawings and specifications
Proficiency in MS Word, Excel, Access and Outlook
Knowledge of construction practices, UFGS, UFC, ASME codes, API, North American and / or international standards and principles related to the design, construction, inspection and repair processes associated with petroleum and oil storage and distribution systems
OSHA Construction Safety certifications and/or relevant industry certifications from API, STI or NACE
2 Year degree or certificate in engineering or construction services related field

Construction Manager Resume Examples & Samples

Supervise and support a Team of skilled and experienced construction management and support staff
Build a team of experienced and qualified staff needed to efficiently execute the project
Provide leadership and direction to the organization
Manage overall project controls function including schedule and budget compliance
Assist in the preparation of Scope of Work Documents and subcontracts as required
Minimum 20 years’ experience related to construction management of all facets of infrastructure
Prior experience working in the Middle East
Prior experience in heavy civil works, dredging and construction of all facets of infrastructure
Engineering Degree is desirable but other degrees will be considered depending upon prior experience
Ability to work with a large team and provide strong management and communications skills

Construction Manager Resume Examples & Samples

Strong skills in construction inspection, preparation of and follow through on resolution of site punch lists
Strong surveying techniques/equipment/computation skills
Strong communication skills to communicate in a clear and concise manner with technicians, engineers, public officials, and other stakeholders
Ability to read and interpret documents such as zoning and construction drawings, bids and leases

Construction Manager Resume Examples & Samples

Minimum of 8 years of progressive experience in positions that manage construction, conduct construction quality control and report with performance review construction assurance
Experience doing similar work in a conflict zone
Willingness to travel in Afghanistan
Ability to work effectively in a fast-paced, stressful environment. In addition, must be flexible, willing to perform other duties and work irregular hours
Able to understand and interpret construction / engineering drawings and specifications, to ensure all construction meets contracted design and specifications
Skilled with programs of Microsoft Office, Microsoft Project, Word, Excel, Outlook and PowerPoint

Construction Manager Resume Examples & Samples

Bachelor of Science in an Engineering discipline, Construction Management, or Architecture required or 10 or more years in a construction management role
5 years of experience as a Construction Manager in an Engineering, Environmental or Construction organization required
Strong working knowledge of pre-design and pre-construction, building systems/components and technology, contract management, project delivery methods, team building and client relationship building required
Intermediate to advanced skills in Microsoft Office Suite preferred
Certified Construction Manager (CCM) preferred

Construction Manager Resume Examples & Samples

Engineering Degree / Diploma in Mechanical Engineering with more than 15 years working experience with reputed consultant / EPC contractor
Working experience in execution of Mechanical and Piping works for Chemical, Petro chemical, Refinery, food and pharma sectors
Good knowledge on IS codes, ASME standards requirement as well as standard Mechanical and Piping engineering practices

Construction Manager Resume Examples & Samples

Assures Jacobs team performance of project personnel and subconsultants meets Client needs and expectations
Monitors project budgets, financial commitments and expenditures
Assures safety policies and procedures are implemented on the project and monitors safety program for compliance
Assures quality processes and procedures are implemented on the project and monitor’s for compliance
Manages and coordinates sub consultant participation on the project
Develops and implements staffing plans in accordance with contract and project requirements
Reviews / approves invoices to the client
Supervises staff (Resident Engineers, Office Engineers, Field Engineers/Inspectors, etc) and provides guidance and mentoring
Communicates project status to supervisor and others on daily, weekly, and monthly basis or when required
Prepares and implements project procedures, safety and quality plans
Attends and presents project status at monthly project review meetings (OPRs)
Manages Accounts Receivable (A/R) and Accounts Payable (A/P) for client and sub consultant invoices
Conducts client expectation surveys
Attends Project Status meetings with Client
May serve as Resident Engineer or site leader on medium or large transit or transportation projects ensuring safety, quality, budget, and schedule requirements are achieved
Manages dispute resolution (including preparation of position papers)
Perform complex schedule and claim analysis
This position requires a minimum of 7 years experience as a Project Manager
This position requires a minimum of 15 years total experience in the construction industry
A BS degree in engineering or related field is required. An MS degree is desirable
SANDAG or other similar transit agency experience is required
Caltrans or other similar public agency experience is desirable
A California PE (or the ability to obtain) is highly desirable

Construction Manager Resume Examples & Samples

Conduct and record site inspections and risk assessments (including Hazard ID, risk analysis and control)
Preparation of manning and cost forecasts
Management of a multi-discipline site team
Responsible for all jobsite labour relations and co-ordinates the activities with representative groups
Supervises all personnel at the site through subordinate leaders
Monitors performance and utilization; provides periodic projects
Supervising and monitoring the execution of all subcontractors’ works to ensure that all contract items and conditions are fulfilled and that the installation is in accordance with plans, specifications and good practices
Overall responsibility of site/construction implementation
Manage the construction implementation in full compliance with Safety, Cost and Schedule as well as QA & QC
Constructability review and recommendation to support engineering and enhance constructability flow
Delegate to field staff such functional responsibilities for construction engineering, craft supervision, contract administration, construction control and field office administration as are appropriate and supervise their performance

Construction Manager Resume Examples & Samples

Responsible for overall project delivery (cost, schedule, quality, information, contracts) on multiple project assignments
Manages the review and approval process for consultant invoices and contractor pay applications and change orders and coordinates with Control Manager for proper posting in reporting program
Resolves complex construction related issues, disputes, and disagreements
Bachelor of Architecture, Engineering, or Construction Management required
5 to 10 years of experience in specifically the healthcare construction (renovation) sector is required
Strong understanding the complexity of hospital MEP, IT, and Fire systems required

Construction Manager Resume Examples & Samples

Manage the day-to-day working, utilisation, implementation and technical consultants engaged on client assignments. From ensuring the correct material turns up before a job, to explaining the work ethics and activities to colleagues
Report progress on projects by suitable media to sector management, maintain and update project reporting, checkpoints and financial reporting to a high standard
Produce reports on each project at agreed intervals, and whenever substantive actions are required
Able to lead motivate and develop a team of engineers
Clear capability to manage complex issues and deliver results
Exceptional ability to build client and other stakeholder relationships and influence at all levels
Ensure that the project team maintain a safe place of work and working environment on clients’ sites
Develop thorough and detailed project execution plans which define scope, schedules, estimates, design deliverables, and procurement plans
Coordinate all project activities between internal process design team, design houses, and contractors
Ensure Change Management process excellence affording cost and schedule control
Ensure compliance with all policies, procedures and technical standards
Work closely with the commercial management team to provide detailed and transparent cost reports, forecasts to complete, quality and SHE reports on a monthly basis
Experience in managing multi discipline projects
In depth knowledge of project management processes and project execution best practices including utilisation of stage gate process approaches

Construction Manager Resume Examples & Samples

CM will work with engineering and the client to develop execution strategies and detailed plans to safely and efficiently execute the work in meeting client, business and project objectives
Preconstruction services include developing a logical work sequence, procurement and subcontract plans that supports construction need dates
Provides support for development of resource loaded schedules and project cost estimates
Must possess leadership and management qualities as both are required to successfully deliver projects
Must have effective communication skills to build consensus with project team members and stakeholders
Directs his staff and contractors on project objectives and manages the work through others to ensure objectives are met
Must have a solid safety implementation experience and successful safety performance record
Familiarity with OSHA requirements is a must
Required to implement a comprehensive safety process on the job site utilizing Jacobs HSE SOPS
Achieving Zero Incident performance is an expectation
Manages all on site construction functions in accordance with the established policies, procedures, systems, and requirements approved by the Company
Monitors performance and utilization. Functions as liaison between engineering and construction
8-12 years of related experience, BS/MS in Construction Management or Architectural / Engineering Discipline is preferred
Relevant experience will be considered in lieu of a formal degree
Completion of OSHA 30 hour training program is desirable

Construction Manager Resume Examples & Samples

Experience with brownfield work
Experience with combined cycle power plant
Strong safety culture

Construction Manager Resume Examples & Samples

Supervise Assistant Construction Manager(s)
Oversee contractors' work as it relates to budget and schedule
Direct activities of architects/engineers
Inform development group and/or ownership of construction status
Prepare cost estimates and budget updates
Review working drawings
Administer change order procedures and contractor progress payments
Control documentation and historical data regarding construction
Ensure overall adherence to the project schedule, budget, lender and/or ownership (partner) requirements

Construction Manager Resume Examples & Samples

Responsible for overall planning, direction, organization and budgeting of all construction or maintenance work
Responsible for project safety, quality levels within time and cost constraints
Responsible for all safety planning associated with the project construction execution methods selection, with support of the Project Manager and Site Health and Safety Manager
Responsible through the constructability coordinator to set up and oversee the constructability process
Coordinate with the client, project management, and project services in identifying required reporting procedures and formats for client and Hatch management needs
Ensure corporate policies and procedures are fully implemented
Establishes project field procedures and objectives within corporate policies and procedures as necessitated by jobsite conditions
Review and approve construction estimates, budgets, forecasts and schedules
Review construction/erection drawings and specifications prepared for the project for economic constructability, develop strategies for erection interfaces, determine appropriate construction methods, and pre-empt problem areas
Ensure the necessary permits and licenses (notice of project, insurance certificates, workers compensation, environmental permits etc.) are identified and obtained prior to the start of construction activities on site
Liaises with the Project Manager and the project core team of design engineers, procurement, planning and scheduling and other personnel and other personnel as required in setting priorities to ensure timely construction performance
Develop site organization and staffing requirements required to execute construction activities within project schedule and acceptable costs
Direct, monitor and motivate subordinate construction specialists in performance and direct activities as necessary to ensure project requirements are achieved
Establish the construction requirements for pre-fabrication and modularization
Ensure adherence to all local regulations and statutory requirements in site activities planning
Assist the procurement team to review contractual agreements with clients, suppliers, and contractors
Liaise with client representatives as required to ensure shutdowns, relocations, tie ins, etc. are planned safely and in a timely manner with minimum disruption
Recommend requirements for construction resources and strategies to meet the schedule in each area
Participates in the labor studies, manpower sourcing exercise and the establishment of the industrial relations strategy
Cooperate with the Pre-Operational Testing Manager in the planning of transfer packages
Coordinate the preparation and issue of the Construction Execution Plan
Experience in Engineering, Procurement, Construction, Management, Commissioning and start-up of major facilities around the globe, at all phases of realization (FEL1, FEL2, FEL3, Execution, Commissioning, and Start-up) - 10 years or more
Demonstrated health and safety management focus in the construction phase of project delivery, and extensive knowledge of health and safety management procedures, safe work practices, and applicable legislation
Minimum five to seven years previous construction management experience in an EPCM managing billion dollar projects
Must have site based experience in infrastructure, energy and mining projects
Strong leadership skills, the ability to lead a team in large multi-million construction projects
Effective report writing skills, planning and organizational skills
Proven communication, negotiation and interpersonal skills with clients on key issues
Extensive knowledge of all phases of construction operations relating to field activities of all engineering disciplines, construction and maintenance practices, procedures and techniques, and applicable codes and standards
Proven business and management principles related to strategic planning, resource allocation, production methods, leadership and coordination of people and resources
Knowledge of electrical equipment and systems is an asset

Construction Manager Resume Examples & Samples

Organize and direct all construction-related activities on a TBM tunnel works project to ensure project is constructed in accordance with design, budget, and schedule; meets accounting requirements, and is completed to quality standards
Conduct and record daily inspections of construction for conformance with design plans/specifications and permits
Plan, coordinate and/or supervise activities of all company personnel on assigned project(s)
Monitor and document the construction process
Identify field conflicts/changes
Track daily quantities
Review pay estimates
Maintain field drawing mark-ups
Prepare daily and monthly reports
Implement and maintain quality standards
Budget management and procurement
Communicating with the client and consultant representatives
Liaising with design teams
Overseeing sub-contractors
A Bachelor’s Degree or equivalent in Construction Engineering, Civil Engineering, or a related field from an accredited college or university is required
A Professional Engineer’s license is required
A minimum of 10 years’ experience in roles such as; Construction Manager, Project Manager, Tunnel Manager
Management/oversight experience from start to finish on at least one tunnel construction project constructed using a TBM
Experience with Tunnel, concrete and major underground civil projects is preferred
Experience with projects involving tunnels and tunnel boring machines, pile driving, deep construction on large active sewers, utility interfaces and relocations, environmental and safety compliance, permits, and rights of way
Ability to read and interpret project construction plans and specifications in multiple engineering and architectural disciplines and to recognize deviations from such plans in the construction process
Ability to establish and maintain effective working relationships with contractors, property owners, representatives from other agencies, and the public
Ability to express oneself clearly and concisely, verbally and in writing
Computer skills relative to daily report writing, email communications, and Excel spreadsheets
Excellent documentation and electric file organization skills
Must be able to work independently and with other inspectors and engineers

Construction Manager Resume Examples & Samples

Monitors project schedule, ensuring project milestones and deadlines are met
Defines site level safety practices and protocol in alignment with organizational standards. Ensures safety procedures are followed and work site is safe for all employees, customers, subcontractors and the public. Champions the journey to an incident, injury and illness free culture and environment. Maintains close partnership with the Health, Safety and Environment department
Supervises on-site personnel, equipment, and subcontractors
Establishes and maintains highly effective relationships with the customer and internal partners
Understands wind turbine technology and basic work practices to help drive efficient cost effective team models that drive customer satisfaction
Responsible for the project site budget and operational efficiency. Establishes the most effective and efficient staffing model to meet operational objectives. Manages costs that impact the bottom line. Implements initiatives that improve efficiency and effectiveness. Responsible for liquidated damages mitigation
Ensures site data is updated and processed in a timely manner in the appropriate information systems for reporting and tracking purposes including summary of construction progress
Responsible for accurate documentation for billing and providing support for efficient accounts receivable
Inspects work during construction to ensure compliance with plans and specifications
Bachelor degree in construction management or equivalent
Several years’ experience as construction or project manager, project lead, or other management experience, preferably in a related service, industrial or manufacturing setting
Technical background required, especially in Substation, electrical instrumentation, hydraulic or rotating heavy equipment. Effective knowledge of technical drawings and schematics
Strong business sense; understanding of the impact of decisions on project budgets
Strong knowledge of safety procedures and management
Excellent leadership skills. Demonstrated ability in coaching, mentoring, motivating and developing employees to achieve a highly aligned, motivated and engaged team
Effective change and conflict management. Proven decision making ability with balanced risk taking. Ability to apply expertise to get results
Functions effectively under pressure in environments of rapid change and conflicting demands and is capable of multi-tasking
Flexibility related to work places (full-time travel to be expected)

Construction Manager Resume Examples & Samples

Solid engineering project management experiences, have good HSE knowledge and engineering design & construction coordination experience
Be familiar in project construction management, especially in construction site management between all local authorities, contractors, suppliers and design institute in project schedule & Progress, safety, construction quality, and technical clarification management
Bachelor degree or above in Mechanical engineering, 5 years above experience on project engineering & construction management, 10 years and above in chemical or light industrial mechanical engineering
Accountable，pre-active, be good in communication & coordination
Familiar with PID drawings, process equipment selection, process piping engineering and construction
Fluent in English listening, reading and written
LI-IRY

Construction Manager Resume Examples & Samples

Promote HSE awareness and ensure that all customer / AMEC HSES requirements are implemented and adhered to
Provide effective and practical construction input into study, FEED, and contract action phases of the EPC project to ensure constructability aspects of project execution are adequately considered via the construction team
Ensure that construction hazards and risks are fully considered by designers and contractors and that the appropriate mitigation actions are implemented during the project execution phase
Coordinate with all project stakeholders, especially within customer, to facilitate the project execution with minimum disruption and hazards to both ongoing operations and the contractor via the EPC package Construction team
Ensure that the PMC construction team maintains efficient and effective communications between the Contractor and PMC to make sure that all reporting requirements are met
Develop close working relationships between all assigned construction team members and the HSES team to provide a consistent approach and effective resolution of issues, and encourage the same degree of cooperation within the Contractor organization
Develop a good team spirit within assigned PMC personnel and encourage team working with the Contractor and other customer groups
Graduate of B.S. Engineering Degree
Minimum 25 years industrial experience
Minimum 5 years in similar position
Leadership and Team Building Skills
Experience in PMC / EPC Organization in Refinery / Petrochemical Industries and have managed major project(s) of value not less than USD $500 million each

Construction Manager Resume Examples & Samples

Ensures assigned construction projects are completed according to the company’s standards for time, cost, and quality
Conducts regular field inspection on assigned projects, ensuring contractors’ compliance with contract documents and takes necessary corrective to ensure objectives are achieved
Reviews and approves contractors’ application for payment as authorized in management approved contract and purchase orders
Schedules and coordinates store equipment and fixture setup activities to ensure timely occupancy of store including: delivery and installation of equipment, utility connections, refrigeration startup, confirm receipt of all required occupancy licenses, and working with operators to receive merchandise
Reviews and approves schedules for construction, equipment deliveries, inspections, and utility connections refrigeration startup, and receipt of all required occupancy licenses as required to facilitate Operations set-up and merchandising activities
Provides design and construction expertise to operations and departments in response to questions in the area of maintenance and repair
Assembles and approves contractor bidder list for each assigned project
Conducts performance evaluation on approved contractors, architects, and engineers at conclusion of each project conferring with management as needed regarding changes in pre-qualified status based upon evaluation
Executes disaster recovery plan for assigned area
Provides budget estimating to operations and departments in research and development of Division annual Equipment Budget (AEB) forecast, including feasibility analysis and cost estimating
Oversees all aspects of design and construction activities for assimilation of acquisition stores within the assigned area
Reviews qualifications and confirms interest of potential contractors
Provides training and mentors less experienced construction professionals
This level is reserved for high potential associates that are candidates for future management positions and takes on leadership role in assigned area by: developing and the administering department budget; developing long-range resource planning and alignment of resources with company’s development; Identifies and evaluates outsourcing opportunities; coordinating construction objectives with other projects throughout the company; creating or assisting in the creation of broad policies and long-range goals; and leading continuous process improvement efforts
Bachelor’s degree with emphasis in General Business or related field or equivalent work experience
8 plus years business and significant consulting management experience
Possess a comprehensive understanding of retail real estate, construction, retail store operations, and retail store equipment
Able to handle the most complex, high profile and diverse projects and/or issues and make decisions with extremely high level risk
Exceptional market analysis skills
Possess excellent negotiation skills
Possess excellent management and leadership skills and the ability to motivate and work with and through others to achieve desired results
Ability to work independently and be able to plan, organize and schedule time and activities effectively to achieve work goals
Strong project management and the ability to manage multiple projects concurrently
Ability to manage multiple projects concurrently
Possess strong communication skills, both written and verbal
Ability to work effectively with and through others to achieve goals and objectives
Must have the ability to represent the Company's interests to outside professionals and contractors
Possess a thorough knowledge of front-end work methods, fund handling and scanning procedures
Must have a good understanding of Company scanning and price maintenance support application systems and practices
Previous experience in retail store operations with a strong background in scan coordination procedures and methods, preferably with a Retail Scanning Company
Must have complete knowledge of front-end company policy and procedures
Understand the completion of store bookkeeping duties
Must have the ability to work with and through others to achieve results. Must work effectively in a team environment. Team and relationship building skills are required
Demonstrated excellent verbal and written communication skills to interface with personnel at all levels effectively. Must be able to communicate concepts, procedures, and systems needed clearly
Must have PC skills and desktop application (Word, Excel, PowerPoint) knowledge
Requires analytical ability
Travel Requirements: 40% travel

Construction Manager Resume Examples & Samples

Candidates must have 20 years or more of Buildings & Infrastructure project experience
Candidates must hold an Engineering Degree Qualification or equivalent from a government recognised institution
Candidates with these certifications are preferred: Certified Construction Manager (CCM), Professional Engineer (PE) or Architect license/certification
Candidates must be proficient in using MS OFFICE
Candidates with experience working within GCC countries (Saudi Arabia/United Arab Emirates/Qatar/Kuwait/Oman) will be given first preference

Construction Manager Resume Examples & Samples

Supervises the total construction effort to ensure the project is constructed in accordance with the design, budget and schedule
Develops quality and workmanship standards and adheres to construction specifications
Provides technical assistance and interpretation of drawings, recommending construction methods and equipment, as required
Logs, references, distributes, and files all related correspondence, drawings, and documents
Plans, coordinates, and supervises on-site functions (scheduling, material control, and day-to-day direction of on-site administrative staff, when assigned)
Ensures all project staff and subcontractors employed to execute engineering-construction tasks conform to applicable work rules and SOPs for security, safety, environmental controls, hazardous materials and underground utilities
Submits as required Construction Reports, to monitor progress against schedule/timelines
Cooperates with visiting Government and DI personnel conducting official inspection visits and surveys and participate in their briefing or orientation
Provides leadership, mentoring, and professional development to assigned staff
Manages the work of teams to procure and construct work
Leads, manages and mentors the assigned technical and professional staff responsible for the facilities construction management of tasks from contract development through construction completion
Knowledge of cost controls, contractual and project management of international construction projects
Thorough knowledge of the Federal Acquisition Regulation (FAR), Defense Federal Acquisition Regulations (DFAR) and related federal and state legislation and regulations
Knowledge of Service Contract Act and Truth in Negotiations Act
Knowledge of international business management and International Traffic in Arms Regulations (ITAR) if required for contract
Knowledge and understanding of the Foreign Corrupt Practices Act (FCPA)
Knowledge of accounting practices including DynCorp’s disclosed accounting practices
Effective leadership and interpersonal skills
Able to travel internationally on short notice to a hazardous environment
Requires a thorough knowledge of practices, standards, and regulations as they apply to the design and construction of the regional camps forward operating bases, and major civil projects
Excellent communication and organizational skills are essential
Has the ability to use Project and Construction Management planning and reporting tools such as Microsoft Project and Primavera
Must possess a current or have the ability to obtain a U.S. Passport before assignment
Possess, or have the ability to obtain a Moderate Risk Public Trust (MRPT) through the Department of State background investigations is a condition of employment. A current MRPT is preferred
Must have at a minimum of fifteen (15) years construction field experience in all phases of Civil and Building Construction or a two (2) year associate’s degree in Construction Management and ten (10) years of field experience
Preference will be given to individuals who have experience in government funded projects in the Middle East and/or underdeveloped countries

Construction Manager Resume Examples & Samples

Coordinates activities between contractors, applicants and inspectors in the field by planning and participating in design review, pre-bid, pre-construction and in-progress construction meetings
Provides design, bid, construction and safety oversight by reviewing design documents, bid documents, contractor invoices and disbursements, creating punch-lists and performing routine site visits
Monitors the delivery of key contract documents (preliminary/final design plans, accepted bids, contractor submittals, invoices and status updates) and uploads them in WT
Verifies current construction projects are in compliance with RREM program specifications, permit drawings and all municipal code requirements
Anticipates demands to align operational priorities
Monitors implementation and compliance of OSHA and CB&I Safety policies
Maintains an open dialog with all contractors in the RREM Program
Develops relationships with key internal/external customers to identify emerging needs
Strong residential home building &/or home renovation experience to estimate all costs associated with reconstruction or rehabilitation of a residential home
Strong knowledge of all local codes, zoning requirements and building standards
Ability to perform a site inspection with little training provided in compliance with local codes and zoning requirements
Proficient in MS word and ability to learn new software on demand to complete project requirements
Must have technical/professional background in QAQC, finance, business management, engineering, architecture, construction management or similar fields
Effective oral, listening, and written communication skills
Ability to complete work assignments independently with minimal supervision/guidance
Strong Customer Service skills required
Has 10+ years relevant experience
Bilingual applicants will be strongly considered and are encouraged to apply
Experience with CDBG/HUD programs, FEMA, and/or other Disaster Recovery programs is strongly desired but not required
Experience with Xactimate estimating software is a plus
Bachelor's Degree Preferred

Construction Manager Resume Examples & Samples

Develop budgets aligned with cost model/corporate expectations with the ability to perform financial analysis, forecasting and reporting
Plans, organizes, coordinates, directs and controls all construction activities for assigned projects in a manner such that there is minimal interruption to the customer’s operation/employees to meet or exceed industry quality workmanship standards
Ability to implement principles and processes for providing customer and personal services. This includes customer needs assessment, quality standards for services and evaluation of customer satisfaction
Ensures company compliance with terms of the contract. Promptly resolves customer concerns and compliance issues and notifies Manager of concerns
Provide support to and works with all contract Environmental, Safety, Health and Quality team members. Proactively pursues quality control opportunities for high profile and large projects
Continually reviews project status with customer, subcontractors, and suppliers to resolve any problems regarding safety, design, quality, scheduling, profitability, or other related issues
Conducts project site visits and develops detailed project notes reflecting necessary project performance requirements
Develops scope of work and scheduling documents for construction projects in accordance with customer requirements, pre-bid walkouts, and specifications. Actively works with subcontractors to ensure adherence to project schedule by reviewing resources, material/equipment lead times and other applicable project constraints
Calculates project completion percentages and reports incrementally as defined and at final completion
Assists JOCC Estimator to negotiate Delivery/Task Order price and performance period with customer PM and/or technical representative
Fully responsible for turnkey construction project and activity compliance including but not limited to security, quality, safety, environmental, workmanship, schedules, costs, customer correspondence, materials procurement, access, staging, temporary utilities, submittals, RFIs, and change orders. Perform routine field inspections to ensure compliance. Facilitates project punch out activities throughout the duration of the project
Regularly attends weekly project status meetings with Chugach and subcontractor personnel. Prepared to report on project projections, project constraints and data requirements for project tracking purposes
Generates receiving reports and collects project closeout documents such as red line drawings, signed completed punch lists, release of claims, asset information, and warranties
Completes subcontractor performance evaluations

Construction Manager Resume Examples & Samples

Constructability review of overlapping subcontracts
Oversee subcontractors’ adherence to the plans and specifications, as well as HASP related to the project
Oversee subcontractors adherence to quality standards, scheduling, and cost control
Prepare daily and weekly construction production reports
Assist the Site Safety and Health Officer (SSHO) with daily safety tail gate briefings and onsite safety monitoring
Maintain an orderly and complete history of the work in monthly, weekly, and/or daily reports as required
Interface with on-site client and their support contractor to coordinate timing of site visits and field activities
Work with Field Project Scheduler to status schedule and plan for future activities
Support earned value management reporting
15 + years of experience working in the field on various construction activities including infrastructure and buildings
A minimum of a Bachelor’s Degree in Construction Management or other related discipline; experience instead of degree will be considered
Experience using earned value techniques a plus
Strong work ethic, team player, self-motivated

Construction Manager Resume Examples & Samples

Lead the construction activities on the island & manage contractor performance
Support the Island Manager in all aspects of island management activities
Management of all construction activities of UZ750, through effective team working with the contractor to ensure the work is performed safely to the agreed schedule and to an acceptable standard
Provide leadership and direction to the IPMT Construction Team personnel to effectively coordinate, monitor, and facilitate the work
Ensure that the assigned scope of work is carried out without any significant HSE incidents and within the project cost, quality and schedule requirements; champion safety in all construction aspects of UZ750 and promote the safety objective that "Nobody Gets Hurt” Promote HSE awareness and ensure that all ZADCO HSE requirements are implemented and adhered to
Lead the UZ750 on-island Construction Team to support the objectives, strategies, obligations and requirements of the UZ750 Project
Responsible for ensuring construction progress and performance are on schedule and as planned by providing construction and execution strategy support to the on-island Construction Team to ensure construction execution certainty
Responsible for all SIMOPS & PTW processes, and manage SIMOPS interfaces with Operations & Drilling on the island
Identify and lead interface management with HSE / drilling / logistics on the island
Manage site constructability and construction input during detailed design and construction
Review and approve EPC contractors construction plans, procedures and schedules
Ensure EPC contractors & sub-contractors are compliant with project safety expectations, policies and procedures
Ensure that material delivery planning by the contractor is in accordance with the agreed schedule
Provide effective and practical site management and construction input during the execution phases of projects to ensure site management and constructability aspects are adequately considered via the construction team
Clearly communicate the short & long term construction goals to the on-island construction team & provide early warning notification of any potential commercial I schedule risk or opportunity to the Onshore Construction Manager I Island Manager for further action
Encourage and recognize good staff performance and ensure that staff are appraised regularly (PDR); Take a lead role in mentoring and training UAE Nationals in Construction Management
Establish contractor’s performance monitoring & reporting for the SoW
Ensure logistics planning by the contractors meets the project needs & facilitate interface with logistics
B.S. or equivalent degree in Engineering or HNC I HND from an accredited' university / college or fully accredited trade qualification
Minimum of 20 years relevant experience in the Oil & Gas Industry
Must have onshore I offshore Client I PMC experience for at least 12 years in similar position
Must have familiarity with latest construction methods, modern project construction management techniques and HSE and Safety aspects; requires specific knowledge in coordinating contract packages, site plan management and tracking construction progress
Middle East experience would be an added advantage

Construction Manager Resume Examples & Samples

3 years of work experience in design, construction or program management on construction projects
Possess problem solving skills
Be a motivated, highly dependable individual that can work under remote direction from Beijing or Tokyo
Ability and willingness to think outside of the box to find creative and innovative solutions prior to and during the construction process to reduce costs and schedules with no impact on quality and reliability
Possess good communication skills in English and have an attention to detail, and be able to maintain high quality standards
Bachelor’s degree in Construction Management, Architecture, Structural, Civil, Mechanical or Electrical Engineering
Experience directly related to the design or construction of large data center facilities, either colocation or client owned/operated
Experience with fast track design/build projects and or multiple significant upgrade projects
Knowledge of Chinese building codes and regulations including Fire Codes, Building Codes, Energy Efficiency Codes, Sanitary Codes and Safety Codes
Experience in power and mechanical system reliability and risk assessment studies (SPOF)
Work experience with global international companies, both in larger APAC region and within US based organizations
Ability to define data center system-level architecture, specify/document performance and equipment requirements to vendors and contractors, communicate conceptual designs, and create/maintain project documentation before, during and after construction

Construction Manager Resume Examples & Samples

Manage the civil and electrical teams including subcontractors , Ensuring that all design standards and delivery programs are being met, work is executed in a safe manner, evaluating performance, quality and noting issues that may result in a claim; present cost/time saving opportunities to project management, and inspecting and documenting the work at installation
Provide support during the bid stage, with construction methodology, support to identify potential partners/suppliers selection as a technical expert; prepare cost estimates of work scope; and help to ensure overall competitiveness of the project’s civil, trackwork and electrical cost within the marketplace
Project planning and coordination of the teams, materials and sub-contractors to achieve the construction program. Plan work activities and develop safety conscience work plans in conjunction with the project schedule, the client requirements and BT design requirements
Develop and maintain minimum inventory of tools, equipment and vehicles to perform works required. This includes providing safety gear and equipment to staff as and when required
Maintain a daily log of activities that document as the project events as they unfold, and submit to the project manager. Attend project meetings in support of project management and communicate relevant information to contractors and employees
Attend site as required during bid and project delivery phases
Minimum 4 years’ experience in engineering, construction management, project management, or related field –preferably within Rail
Proven leadership ability
Excellent stakeholder management

Construction Manager Resume Examples & Samples

Responsible for overall management and coordination of construction equipment for the project to maximize productivity and maintain schedule
Develop solutions to complex problems that require a significant degree of innovation and ingenuity
Develops procedures as needed. Functions as liaison between multiple project managers, construction and contractors. Provides constructability input and construction planning

Construction Manager Resume Examples & Samples

Ensure that the Health, Safety, Environment, Security (HSES) and quality policy is understood and implemented by all supervised staff and construction contractors
Manage the construction work by Subcontractors, ensuring that the work is done in accordance with the specifications, calculations, drawings and terms of the contract
Make sure the construction is done in accordance with the specifications and engineering drawings and establish the necessary inspection procedures to check the required quality
Oversee the completion and Turnover of the Permanent Installation, and obtain Client Acceptance of the completed works
Etc
Bachelor / Master Degree in a relevant technical discipline
Minimum 15 years’ experience in the design and construction of chemical, petrochemical, oil & gas, refinery facilities of the EPCM environment and at least 8 years of experience in a similar position
Experience in managing construction activities on site within the Oil & Gas (especially refining) industry
Proven record of experience in construction management of modular projects
Excellent command of Spanish and English languages
Good interpersonal skills with sound written and oral communication skills, ability to communicate in an articulate manner with clients, consultants and subcontractors
Highly motivated, well organized, resourceful and proactive
Previous Amec Foster Wheeler experience would be an advantage
Immediate availability to join the project
Only applicants currently eligible to live and work in Spain can be considered

Construction Manager Resume Examples & Samples

Coordinate, manage and complete multiple concurrent turn-key projects of varying size
Attend contractor’s project meetings and maintaining accurate records of meetings, schedules, and requests
Manage project budgets and bring the project in at the dollars and hours allotted to the job, interact with the district sales staff to confirm labor estimates on new and retrofit projects
Will identify project change orders
Anticipate and identify problems early and implements solutions
Assist with collecting on project invoices and resolving disputes
Monitor district performance, resolves problems, fine-tunes plans to changing conditions and report difficulties
Ensure compliance with project closeout requirements, AHJ approvals, customer training and closeout documentation
Assist in proposal activities, selection of subcontractors, maintain project documentation, control equipment allocation and project manuals
Retain copies of contracts, change orders, special commitments, ship dates, completion dates and other elements necessary to monitor the project
Maintain a set of report and working drawings where applicable, consulting with local building inspectors, interfacing with owner/customers
Conduct construction meetings, maintain safety program, arrange equipment delivery, scheduling and change order management and project close-out documentation

Construction Manager Resume Examples & Samples

Soil/sediment remediation
Landfill capping systems
Earthwork and site development
Building decommissioning and demolition
Sheet pile systems
Trenching and mechanical piping projects
Working with subcontractors
Managing day-to-day activities on large construction/remediation projects
Previous construction management and construction oversight experience required
100% travel required
Strong approach to safety
Skilled at heavy equipment operation and remedial construction

Construction Manager Resume Examples & Samples

Achieving a safe working environment for staff and on-site contractors
Timely reporting and management of all accidents, incidents, near misses, and safety statistics
Assuring adequate construction site security
Monitoring and supporting the completion of all construction activities
Administering construction contracts
Controlling construction costs
Working with the project construction contractor to monitor construction schedule
Working with the project construction contractor for overall quality of the field construction
Insuring that all construction complies with engineering drawings and specifications and company quality standards
Coordinating all construction activities with operating plant personnel to avoid disruption of operations at the existing plant
Maintaining construction documentation, correspondence, files, test records and "As-built" drawings
Issuing Work Permits (including Hot Work, Confined Space, etc.) as necessary, for construction areas on project
Manage the mobilizing the construction site
Reporting construction progress, costs and problems to the company Manager
Keeping Project Management well informed of external problems that are impacting construction
Insuring proper receipt, storage and transfer of company purchased materials
Oversee the preparation of facilities for transfer to the company operating group
Evaluating and reporting contractor performance

Construction Manager Resume Examples & Samples

Plans, organizes, and directs activities concerned with the construction and maintenance of structures, facilities, and systems
Confers with supervisory personnel, owners, contractors, and design professionals to discuss and resolve matters such as work procedures, complaints and construction problems
Manage site safety including performance of safety audits
Provide constructability feedback during design and walk down
High level of knowledge of office building greenfield construction
Highly articulate, have clear and analytical approach to problem solving, and strong decision making abilities
Ability to navigate Web-based construction management software (often provided by the client). Must have experience with setting meetings, organizing agendas, and keeping minutes for projects records
Must thoroughly understand and utilize Information Technology in the performance of work including Internet, Intranet, Microsoft Windows OS, Adobe Acrobat, Microsoft Office Suite and Microsoft Project

Construction Manager Resume Examples & Samples

Minimum 10 years experience as Construction Manager
Experience in Pharma Plant
Fluency in French and in English is a mandatory requirement

Construction Manager Resume Examples & Samples

Establish and manage schedules, plans, and budgets consistent with the proposed project financial goals as required for project management, engineering, procurement, manufacturing, shipment, collections, billings, installation, start-up, training, warranty, documentation, subcontracts and purchases and all other project activities required to achieve positive project results
Develop and implement plans (for example, the Risk/Opportunity database) to improve project results beyond established budgets and results
Monitor, control, and report monthly all financial aspects of the project consistent with the contract requirements and established project management procedures to attain established goals
Monitor, recommend, and initiate when necessary, changes to or corrective actions for commercial issues, product design, manufacturing and/or services to assure compliance with contract requirements, and to maintain or improve project performance
Establish and maintain partner interfaces to achieve the goals of the joint venture and system end user
Anticipate and satisfy the partner and end-user needs, to the fullest extent possible, while operating within established policies, procedures and commercial guidelines
You hold a Bachelor's degree in Civil Engineering or equivalent. An MBA and PMI Certification will be considered an advantage
You cumulate a minimum of seven (7) years of project management and/or project administration
You possess knowledge of and experience with risk and opportunity assessment tools and in cost recovery management
You have a background in developing and administering resource plans and budgets
You possess experience and knowledge of Project Management skills, including processes and procedures, customer interface, schedule management, scope management, commercial management, personnel administration, and negotiation
You have good knowledge of MS Office Package, MS Project, Working Knowledge of Primavera, BT internal Tools (DOORS)
You possess excellent solving problem skills
You demonstrate good interpersonal, management skills and techniques
You are resourceful and creative
Your teamwork skills are strong
You are persuasive
You are customer service oriented
You possess excellent English communication skills, both written and spoken

Construction Manager Resume Examples & Samples

Monitor construction schedule and report on start, completion, and potential delays
Log RFI’s and respond, review or monitor as needed
Monitor construction schedule and quality through evaluation of progress photos and reports
Walk project for completion, generating and managing punch lists and ensuring work is completed in accordance with plans and in a timely manner
Perform consistent quality control checks by conducting site visits to monitor progress and adherence to approved plans
Monitor compliance with established quality standards and work schedules through regular site inspections
Monitor schedules for assigned communities to ensure home production milestones are met and all approval contingencies are satisfied

Construction Manager Resume Examples & Samples

Executes construction activities in conformance with project drawings, specifications, schedules, construction budget, procedures, quality requirements and safety standards
Controls project schedule and cost through the efficient coordinating with all construction contractors by efficient use of all construction resources including manpower, materials, tools, and equipment
Prepare construction management strategy and execution plan for the site
Provides input for the development of project integrated schedules as project progresses while coordinating with the construction contractors
Ensures that daily and weekly short-range planning is maintained by contractors
Reviews design scope and approach with regard to constructability and submits recommendations for changes
Evaluate manpower levels provided by the construction contractors to attain schedule milestones and monitors manpower levels to ensure conformance with the construction plan
Monitors contractor’s productivity in relation with cost/ schedule and implements appropriate action to maintain maximum labor productivity and cost/ schedule effectiveness
In consultation with Project Service Manager, controls change/scope creep, ensuring that all scope changes are quickly and properly documented and that change orders are approved prior to the performance of work
Assists the Project Managers and Project Director in the overall administration of labor relations policies
Plans and manages the project’s temporary facilities
Ensure that contractors’ construction equipment use effectively and maintenance program
Maintains an effective plan for the supply and control of contractors tools and other supplies through site superintendents
Ensure all contract compliance at site and work with construction contractors
Administers, trains, and motivates all personnel during construction execution through the site superintendent and foremen
Proactively coordinate all material delivery, handling and construction through efficient job site planning
Plays a key role in the development of the safety culture on the project, making safety a natural part of all work performed
Implements the site safety and security procedures and project work rules
Remains knowledgeable of KMCT safety policies and procedures and performs assigned duties in a safe manner, while supervising others, has responsibility for their safety and ensures that they comply with established safety policies and procedures and practice safe work habits
In consultation with Quality Lead, maintains quality of all work in accordance with the KMCT standards as specified in the design documents

Construction Manager Resume Examples & Samples

CITB SMSTS
Temporary Works Supervisor
Fire Warden
HS(G) 47 & NEC 3 Form of Contract
First Aid Certificate
UKPN and/or National Grid Substation Access authorisation
BESC
CPCS Appointed Person (Lifting Operations)
Temporary Works Coordinator

Construction Manager Resume Examples & Samples

Prepare costs budgets and schedules based on conceptual plans for building improvements
Inform property management and ownership of construction status
Review construction drawings
Prepare consultant and construction contracts
Interact with building tenants and adjacent landlords to schedule disruptive work
Monitor construction progress and participate in weekly meetings and site visits

Construction Manager Resume Examples & Samples

Responsible for Phase 2 design procurement delivery (cost, schedule, quality, information, contracts) on multiple project assignments as assigned
Responsible for Phase 2 design development and reviews from conception through completion (both large and small) in accordance with program objectives as assigned
Responsible for all Phase 2 budget, schedule, scope development, design and construction contracts, documents, procedures and controls for assigned projects as assigned
Participates in the review and approval process for Phase 2 consultant invoices and contractor pay applications and change orders and coordinates with Senior Project Manager and Control Manager for proper posting in reporting program as assigned
Attends or chairs assigned weekly Phase 2 progress meetings; issues meeting minutes and reports during design
Reviews status and monitors variances of the construction project database relative to scheduling and cost control reporting in design and construction phases as assigned
Excellent communication skills as this position is client and stakeholder facing
5 years of experience as a Project or Construction Manager in an Engineering, Environmental or Construction firm as a Owners Representative required
Strong working knowledge of procurement pre-design and pre-construction, building systems/components and technology, contract management, project delivery methods, team building and client relationship building required
Active Homeland Security HSPD-12 Clearance preferred
Active Clearance on Federal Projects within last two years preferred

Construction Manager Resume Examples & Samples

To verify that the drawings and specifications provide adequate instructions for the work and advise the Project Manager of any deficiencies or clarification needed
To ensure Construction Workpacks are issued in line with Amec Foster Wheeler procedure & issued for the execution for the works in a timely manner to meet schedule requirements
To ensure adequate and qualified supervision and skilled labour resources are engaged to meet schedule requirements
To ensure, before any variation work is carried out by a sub-contractor that an authorised instruction is given by the Project Manager
To hold regular meetings with Project Management, Client and the various sub-contractors to review progress, resolve problems, etc
Commitment and promotion of all Amec Foster Wheeler’s Values - Sustainably delivering excellence, Never compromising on safety, Acting with integrity through the realisation of company and project Health, Safety, Environmental, Quality and Ethics systems, policies and procedures

Construction Manager Resume Examples & Samples

Manage and coordinate the infrastructure construction activities for single family residential development including scheduling contractors, verifying timelines, determine quantities and criteria for additional work
Inform the responsible contractors of nonconformance with the construction plans and technical specifications and monitor corrective actions
In conjunction with the contractor, review the staffing, equipment and tools and the availability of materials to meet the schedule and adjust schedules to meet Owner and builder requirements as needed to advance the completion of the lots
Schedule and conduct weekly coordination meetings with contractors, suppliers, engineers and construction team to discuss progress and resolve technical and schedule issues
Monitor and control the Master Schedule and coordinate with Owner’s Project Manager in reviewing construction costs and ETC
Assist the Owner’s Project Manager in checking and approving the Status of Work Progress Instalments and contractors’ applications for payment
Assist the Owner’s Project Manager in evaluating scope changes or request of extra works submitted by contractors or required by the Owner
Coordinate collection of as-built deliverables and final certificates needed for Substantial Completion of lots and sale to Builders
Assist the Owner’s Project Manager with close-out of contracts and purchase orders including resolution of any pending issues and/or claims with contractors and suppliers
Experienced in scheduling and subcontractor coordination
Leadership, commitment and strong technical background
Ability to plan, control and monitor design, procurement, construction, commissioning and validation activities
Excellent written, communication and organizational skills and excellent oral, strong interpersonal and negotiation skills
Excellent problem solving and team working skills including being able to rapidly engage with a team
General development business acumen
Degreed in Civil Engineering or Business Administration with emphasis in Construction Management preferred
At least 10 years of experience, the candidate has preferably spent the last 10 years in the role of Construction or Site Manager for infrastructure construction associated with single family residential developments is required

Construction Manager Resume Examples & Samples

3 years of experience in engineering design, construction management, manufacturing, commissioning or program management in mission critical facilities
Be a motivated, highly dependable individual with limited oversight
Ability to define data center system-level architecture, specify/document performance and equipment requirements to venders and contractors, communicate conceptual designs, and create/maintain project documentation before, during and after construction
Ability and willingness to think outside of the box to find creative and innovative solutions prior to and during the construction process to reduce costs with no impact on quality and reliability
Possess excellent communication skills in both English and Japanese, have an attention to detail, and be able to maintain high quality standards
Knowledge of Japanese building codes and regulations including Fire Codes, Building Codes, Energy Efficiency Codes and Sanitary Codes
Work experience with global international companies, both in larger APAC region and with US based organizations

Construction Manager Resume Examples & Samples

Assure implementation of plans and specifications
Assure construction activities are in accordance with contractual documents and are completed within budget and schedule
Overall administration of project
Bachelors degree in Engineering
At least 12 years of related experience
Professional Engineer license (PE) required

Construction Manager Resume Examples & Samples

Responsible for quality control deliverables
Oversees utility coordinators
Manages Service-Level Agreements with construction vendors and subcontractor
Provides the Senior Project Manager (SPM) with accurate and timely status reports, ensuring SPM is fully aware of all issues
Supports the resolution of program issues and tracking of progress updates
Provides on-time and high quality construction planning and execution
Supervises construction progress, ensures quality standards and completion dates
Monitors and maintains the quality of the execution projects by performing in-process and final quality checks
Develops MOPs for each project and review Method of Procedure (MOP) with customer prior to start of project
Interfaces with the SPM as required to complete projects, clarify project status, and meet customer needs

Construction Manager Resume Examples & Samples

Minimum three (3) years of telecommunications/wireless construction experience
Knowledge of Outside Plant Construction techniques (aerial & underground) for SCS
Working knowledge of NESC, NEC and OSHA standards
Knowledge of construction management process
Knowledge of site acquisition procedures, including regulatory and permitting process

Construction Manager Resume Examples & Samples

Manage the pre-construction and construction phases of the OSP project deliver on time, on budget, within quality and safety standards. Must have a strong understanding of Underground and Aerial fiber. A strong background of 7+ years of work experience with OSP fiber would be nice, but not a must. Resolve OSP roadblocks while supervising construction crews is a must
This person must be able to full understand OSP fiber. The majority of this persons day will be spent overseeing the installation of OSP Fiber. Must understand the basic construction codes, and standers that accompany the construction of Underground and Aerial fiber. The need to know safety standers/codes and be able to inforce safety
Manage third party pre-construction and construction suppliers, manage and meet pre-construction and construction schedules, intervals and due dates, Inspect and assure construction work quality and crew safety will be the basic needs of this CM

Construction Manager Resume Examples & Samples

Supervises and coordinates projects involving construction, alteration or large scale repair of buildings and structures
Provides supervision, coordination and inspection of work in progress for compliance with plans, codes, and standards and for compliance with schedules and cost parameters
Schedules and coordinates all construction processes, including the oversight and coordination of inspection staff and quality acceptance testing
Defines and implements construction phase communication procedures requirements
Develops a checklist for contract deliverables and monitor contractor compliance with contract requirements
Conducts meetings to confirm progress, reviews issues and actions, quality and safety, and resolves questions
Defines job site management information systems and time, cost and quality systems; procedures for retrieval and processing of information, as well as documentation requirements
Establishes procedures, document and log all RFI/Clarifications received from the contractor and the related response by the A/E. Works with the contractor to find potential solutions; monitors the response time of the A/E; reviews the A/E response for appropriateness; and notes any cost or time impacts
In conjunction with the architect, works closely with the general contractor and client's facilities operations personnel to implement commissioning requirements included in the contract documents
Implements contract requirements relative to record document turnover and retention
Implements and manages occupancy/start-up requirements
Prepares a Final Acceptance Report and Recommendation for the client
Receives from the contractor operation and maintenance manuals, warranties and guarantees for materials and equipment installed in the project, and coordinates reviews with the architect and the client’s facilities operations staff
Coordinates required equipment and operations training of facilities operations
Meets with the contractor on a monthly basis to review the contractor’s applications for payment
Conducts a detailed analysis of the contractor’s schedule to determine whether the proposed schedule can be realistically achieved and to assess the overall status. This should include a schedule impact determination of suspension of work, concurrent delays, compensable and non-compensable delays, as well as a recovery schedule if it should be required during the course of a project
Conducts weekly schedule analysis of the contractor’s look-ahead
Defines procedures for management of schedules to avoid risks
Administers and understands Float, its use and legal implications
Oversees the delivery and issue of materials, tools, and equipment; worker productivity and safety; and the quality of construction
Monitors the project safety plans and implementation of safety plans for own employees, as well as that of contractors
Develops a communication plan with the client, including monthly reports, project management reports and various schedules and cost control reports, as well as the matrix of responsibilities for all team members
Experience with management and oversight of design-build construction delivery
Experience and active engagement with partnering protocols on construction projects
Credentialed as a Certified Construction Manager
Credentialed as a LEED Accredited Professional
Advanced degree in Construction Management

Construction Manager Resume Examples & Samples

Supervisor, Installation/Service Employees responsible for the execution of the installation project plan and service schedule including equipment delivery, interface with other trades, and routine servicing to successfully complete projects while exceeding customer’s expectations
Working Supervisor with functional responsibility for small team of para-professionals
Combines working knowledge of technical/professional principles and concepts with in-depth knowledge of team objectives
Ensures the quality and service of self and others
Manages workflow to accommodate volume and special project demands

Construction Manager Resume Examples & Samples

Organise and manage the construction of the track in conformity with the details design, the planning and the QA/QC system
Develop and implement the execution plans and procedures for the trackwork installation
Co-ordinate all technical issues especially in terms of constructability, feasibility, BOQ, methods and resources
Follow up investigations in the event of any failure
To implement his task, the Construction Manager is responsible for defining the necessary resources (human and material) in line with the WP budgeted figures
Co-ordinate with the procurement teams for all local purchases
Participate to the preparation of the baseline programme and other related schedules and subsequently to implement the activities accordingly and report on the progress
During the installation, define, support recruitment, purchase and follow up the necessary resources, means and materials and equipment
Ensure that qualified, competent and well trained personnel are assigned to their discipline
Supervise through his field-engineers/supervisor the performance of all his personnel
Participate from the construction point of view, to the analysis of any contractual issue (EI, VO, Claims) and to provide the contract people and PM all required inputs for pricing and negotiation
Co-ordinate with the TSA/Logistic Manager for the implementation of the TW construction needs
Participate to the handing over process
Liaise with the other designated contractors (about various civil contractors works and other third parties works) to facilitate the work progress
Manage the construction progress meeting with the Client
Optimise the trackwork construction work package for the benefit of the overall Project
During the installation, the Construction Manager is required to organise the tasks, in a competent and consistent

Construction Manager Resume Examples & Samples

Ability to develop robust execution procedures, and deliver aligned to 3C Improvement Plan
Never compromise HSE or quality standards to achieve tight deadlines
Take accountability of the sub-contractor / third party performance during life cycle of Project and performance manage accordingly at individual level in order to build an effective team

Construction Manager Resume Examples & Samples

Supervise field construction teams; includes both company and contract work groups
Provide assistance to Construction Director in coordinating construction activities for pipeline work
Provide proactive management in scheduling and coordinating field related construction activities for pipeline and preparation of data for reporting
Maintaining the highest standards for HES performance
Other duties and projects assigned as necessary
Degree/ Diploma in Engineering
With 15+ years’ experience in pipeline construction project scope and worked as client representative/ PMC employee
Thorough knowledge of pipeline systems and construction in relation to surface equipment, including tanks, valves, positive displacement and centrifugal pumps, electric motors, gas engines, and other pertinent equipment
Sound knowledge of API, ASME, OSHA, and DOT codes and standards with an ability to apply that knowledge to pipeline projects
Ability to follow and apply new technological developments in the pipeline industry, supervise and/or repair mechanical problems on pipeline equipment
Ability to lead Root Cause Failure Analysis, implement preventative/predictive maintenance
Strong interpersonal, communication, analytical and project management skills

Construction Manager Resume Examples & Samples

Possess technical competence, skill and knowledge of the construction industry
Possess a working knowledge of Safety procedures, practices and standards
Build relationships and create teamwork within the company, and the project team
Certificate in discipline field is preferred

Construction Manager Resume Examples & Samples

Actively participate in development of a construction HSSE culture that makes safety and environmental awareness a natural part of the job
Understand contract requirements
Develop a construction organizational plan commensurate with the requirements of the Project
Visit sites for pending projects and evaluates site conditions and extraordinary requirements
Coordinate and interface with others as required to execute the construction plan and assure that labor, equipment and materials are available to support the construction effort
Assure that construction work is performed within the budget and schedule constraints of the project controls change/scope creep, ensuring that all scope changes are quickly and properly documented, and that change orders are approved prior to the performance of work
Monitor and controls cost, schedule, progress, and productivity including analyzing deviations and taking action to correct negative trends
Manage scope of work by identifying change conditions or work outside of scope
Ensures subordinate personnel receive progressive training to enable them to assume additional responsibilities
Ensure performance evaluations are conducted on assigned personnel
10 + years in the construction field with 5 + years previous management level experience required
Training and experience in managing on-site industrial safety and personnel issues

Construction Manager Resume Examples & Samples

Understands contract requirements
Manages the contract with client to ensure obligations are met, contract changes are captured and costed and build client relations
Prepare Construction Execution Plan and insure all site personnel are trained in accordance with the execution plan
Responsible for Front Line Business Manager on site
Accountable for the functional direction, coordination, and performance of all on-site construction operations and support departments
Assures the development and implementation of the Site Safety Program and builds a culture that makes safety and environmental awareness a natural part of the job
Responsible for all site budgets, cost and schedule
Responsible for assuring implementation of project procedures for all site construction departments
Responsible for overall site management of support departments i.e. Cost/Schedule, Procurement, Safety, Field engineering/Supervision, Subcontracts
Approves final subcontract documents and contracts
Assures site Quality Control Program is developed and implemented
Assures implementation of the construction erection plan by site supervision
Responsible for material purchase final approvals
Assures the preparation of cost forecasts are coordinated and submitted with all site departments
Responsible for initiating site project team building
Responsible for day-to-day coordination with client counterpart on site
Assures the proper implementation of the project Environment Control Plan
Conducts site walks for Safety with team members and client
Coordinates day to day with home office Project Management
Coordinates with construction functional management
Assures implementation of weekly site schedule meetings and 90 day look ahead
Assures lessons learned are captured and documented to home office

Construction Manager Resume Examples & Samples

Provide oversight of construction activities to modify existing facilities, including utilities, equipment installation and exterior improvements
Arrange worksite and equipment access/shutdowns, obtain permits, and develop project support schedules to support subcontractor activities and minimize interference with others’ work
Work with Project Manager and other Facilities staff to manage activities of subcontractors, LBNL in-house Construction Services staff and vendors performing work, providing services, supplying materials or equipment for the project
Monitor work and inspect construction to confirm it is performed in accordance with the specifications, drawings and terms of the subcontract
Ensure all work is performed in a safe manner in compliance with LBNL and DOE health and safety policies and other applicable Federal, State, and local fire, health, safety, and environmental protection policies
Coordinate construction with site safety inspectors, EH&S staff, building managers, and quality inspectors, applicable Authorities Having Jurisdiction (AHJs), keeping all concerned advised of schedules and status
Support the Project Manager in the review of contractor submittals, Requests for Information (RFIs) and change order requests
Serve as liaison with LBNL clients to keep them informed regarding construction activity and ensure client needs are being met
Develop construction schedules, evaluate construction estimates, review contract modifications, and verify work performed matches contractor progress payment requests
Review pre-construction plans and specifications for constructability, operability, maintainability and cost effectiveness
Ensure “as built” drawings are completed on assigned construction projects
Provide oversight of construction activities to build new or modify existing complex facilities including laboratory, office, data center or utility projects
Contributes to the development of new procedures for construction/project management activities within the Facilities Division
Lead and collaborate with multiple stakeholders to resolve complex construction interferences and conflicts
Knowledge equivalent to Bachelors Degree in Engineering, Architecture, Construction Management or functional specialty closely aligned with relevant program and extensive related professional technical experience preferred
Demonstrated experience as a superintendent or professional construction manager coordinating remodel and new construction projects, preferably on complex buildings for government or institutional use
Knowledgeable of State and local applicable building and safety codes with demonstrated experience in applying and/or performing plan checks and code compliance reviews. Broad knowledge of California Building Codes and industry standards and practices in the facilities arena
Working knowledge of the regulations associated with asbestos abatement (EPA & CAL OSHA). Working knowledge of the UBC and Fire Code as related to commercial and industrial buildings. Understanding of biological and chemical hazards. Knowledgeable in the area of construction safety consistent with OSHA, NEC etc. standards
General understanding of major environmental mandates and regulations such as RCRA, Clean Air Act, Clean Water Act, CERCLA as well as DOE Orders pertinent to environment, health and safety protection
Ability to plan, organize and estimate multi-craft institutional building renovation/tenant improvement projects
Ability to interface between engineers, clients and craftsmen. Demonstrated client relationship skills with excellent interpersonal skills for customer-focus approach
Demonstrated ability to use computers effectively for record keeping, report writing and communication
Demonstrated experience in planning, prioritizing, organizing and applying time management skills to handle multiple projects at once
Experience applying analytical and problem solving skills to complex problems
Demonstrated ability to take initiative, use sound judgment and provide solutions to ensure results
Demonstrated skills in conflict resolution, balancing workload, and performing effectively under fluctuating priorities
Ability to work independently and as part of a diverse team
Must have a valid California Driver’s License
Knowledge equivalent to a Bachelor's degree or equivalent experience and a minimum of 10 years related professional technical experience
Proven history in providing oversight in construction activities and resolving complex technical problems that requires in-depth evaluation and analysis
Electrical background including elect engineering degree or licensed electrician is highly desirable
Building systems commissioning or MEP coordinator background

Construction Manager Resume Examples & Samples

Lead construction involvement during FEED and the Engineering phases of an EPC project providing construction input to constructability, organisation and site set-up, site logistics and scheduling, work breakdown and packaging as well as the appointment (if required) of subcontractors and suppliers
Where appointed, represent and lead FWUK OU on the construction site and organise, administer and control site activities within a defined construction area in accordance with, the relevant legislation, (includes CDM Regulations, The Factories Act, Construction (Health Safety and Welfare) Regulations, Health and Safety at Work Act, or Specific Country equivalents) and FWUK OU and Client requirements
Where FWUK OU has the role of Principal Contractor as described within the CDM Regulations (or in-country equivalent), the Construction Manager is appointed to assist with the responsibilities of Principal Contractor at Site
Be fully familiarised with the contract requirements, FWUK OU policies and procedures and ensure that those requirements relating to the site operations are implemented on behalf of and under the direction of the Resident Site Manager
Ensure that the FWUK OU Health, Safety, Security, Environment (HSSE) and quality policy is understood and implemented by all supervised staff and construction contractors within a defined construction area
Ensure that the project achieves its objectives in respect of HSSE, quality, cost and schedule within a defined construction area
Agree, establish and maintain effective communication and coordination between construction site and home office task force / departments
Promote FWUK OU by demonstrating professionalism and efficiency, establishing credible client and local contact working relationships
Support, promote, and champion the FWUK OU core values throughout Project Execution
Degree qualified
Oil and Gas
Petrochem
FEED and EPC
Middle East
Major Clients e.g. ARAMCO, ADNOC, Exxon Mobil, Shell etc

Construction Manager Resume Examples & Samples

Safety [EH&S, OSHA],
Quality [TQM, MI programs],
Budget [SAP, K base estimating and field cost control]
Schedule [MS Project, P6, master plans] including acquiring resources for staff and scope execution [contract tender process, administration] as well as coordinating the efforts of team members and third-party contractors or consultants
Associate's Degree from an accredited program
Minimum of 3 years of Contract Administration experience/management of field construction
Minimum of 3 years of experience with vendors and contract labor suppliers in a commercial or industrial arena
Experience leading meetings on Cost, Timekeeping, Staffing, Safety and other topics as they are identified
Minimum of 2 years of experience utilizing MS Excel to create / edit spreadsheets, PowerPoint to create presentations, and Outlook or similar email platform to manage a calendar, schedule meetings, etc
Bachelor’s degree or higher in Engineering or Construction Management
5-10 years of Field Contract Administration experience
Field construction project management experience
Experience working in a chemical manufacturing facility
Sound knowledge of commercial/legal contract language structure

100

Construction Manager Resume Examples & Samples

Lead the design-build team in the design phase, from schematic drawings to 100% construction drawings, through construction phase while working with all stakeholders
Contract Administration – process contractor pay applications, evaluate and process change orders, analyze and maintain tracking sheets and records, perform inspection walks with bank inspectors, inspect and approve work in place, document stored materials and monitor punch/warranty work
Manage Requests for Clarifications (RFCs), coordinate responses and track requests to resolution
Prepare monthly project reports
Maintain project management logs (RFIs, RFCs, PCOs, changes, submittals, field instructions, Non-compliances, safety and close-out)
Ability to organize and manage contractors on complex projects and coordinate with public agencies
Thorough knowledge of engineering and construction principles, practices and procedures, applicable laws and government regulations, principles of management and supervision and procedures and policies of departments and facility
Experience in the public contract code arena
Design Build experience

101

Construction Manager Resume Examples & Samples

Lead the design team in the design phase, from schematic drawings to 100% construction drawings, through construction phase while working with all stakeholders
Manage and resolve change order requests & problem issues and react to feedback from client personnel, prepare reports on project details and communicate overall project goals and details to client manager
Prepare Monthly Project Reports
Maintain project management logs (RFIs, RFCs, PCOs, changes, submittals, field instructions, Non-compliances, safety, and close-out)
Familiarity with accepted buildings practices, materials and techniques, knowledge of common and general code requirements, ADA requirements, mechanical systems and components, permitting processes and requirements, market pricing and lien waivers
Community College Experience
Ability to organize and manage contractors on complex projects and coordinate with public agency
Possess a thorough knowledge of contract administration and office procedures

102

Construction Manager Resume Examples & Samples

Previous construction management of large infrastructure projects
Advanced understanding of project phases and management
Understanding of both equipment and human resource capability and productivities
Ability to manage and lead a diverse team
Understanding of crisis management, including response options
Understanding of and ability to follow Company & Client policies and procedures
Ability to manage conflict between contractors and supervisors
Ability to reinforce rules and recognising good performance i.e.. Health, quality and safety
Understanding HSE regulations and construction standards
Ability to implement cost and time control measures
Ability to negotiate contractual matters

103

Construction Manager Resume Examples & Samples

Minimum of 10 years of construction and/or project management related experience
Proficiency with Web based Interactive programs and Microsoft Office (Outlook, Word, Excel, Project)
Familiarity with government contracting procedures
Due to the nature of the work, candidate must be a US Citizen or Legal Permanent Resident (Green Card Holder)

104

Construction Manager Resume Examples & Samples

Familiarity with construction management software packages
Competent in conflict and crisis management
Leadership and human resources management skills
Expert knowledge of building products, construction details and relevant rules, regulations and quality standards
BS degree in construction management, architecture, engineering or related field

105

Construction Manager Resume Examples & Samples

Requires deployment to project sites in Antarctica during the Austral Summer (Oct - Feb)
Due to limited medical facilities in Antarctica, candidate must pass a comprehensive series of medical examinations and tests prior to deployment
Leidos is a global leader in the integration and application of information, technology and systems working to solve the world's toughest challenges in the civil, health, defense, intelligence and homeland security markets. The company's 33,000 diverse employees support vital missions for government and commercial customers in 30 countries. Headquartered in Reston, Virginia, Leidos reported annual revenues of approximately $10 billion for the fiscal year ended January 1, 2016 after giving effect to the recently completed combination of Leidos with Lockheed Martin's Information Systems & Global Solutions business (IS&GS). For more information, visit www.Leidos.com. The company's diverse employees support vital missions for government and commercial customers. Qualified women, minorities, individuals with disabilities and protected veterans are encouraged to apply. Leidos is an Equal Opportunity Employer

106

Construction Manager Resume Examples & Samples

Plan, schedule and coordinate construction procurements, and supervise field construction activities involving general construction and/or trade subcontractors
Take responsibility for budget, schedule, quality and safety throughout such activities, utilizing company resources for guidance and support
Maintain accurate daily record of construction site activity and produce required reports on progress, safety, quality, schedule and budget status
Coordinate with other project team groups such as design, procurement and accounting
Work on small projects, or as support to more-senior staff on larger, more complex projects
Bachelor's degree in Engineering, Architecture, Construction, Construction
Construction or design certifications
Ability to interpret construction schedules

107

Construction Manager Resume Examples & Samples

Prepare Construction Execution Plan and insure all site personell are trainedin accordance with the execution plan
Accountable for the functional direction, coordination, and performance of all on-site construction operations and support departments.·
Assures the development and implemention of the Site Safety Program and builds a culture that makes safety and environmental wareness a natural part of the job
Responsible for overall site management of support departments i.e. Cost/Schedule, Procurement, Safety, Field Engineering/Supervision, Subcontracts
Responsible for day to day coordination with client conterpart on site

108

Construction Manager Resume Examples & Samples

Support the Project Manager in the management and supervision of all construction, pre-commissioning and site related activities in the execution of the Project to ensure the project is completed
Comply with statutory requirements and the Amec Foster Wheeler Health, Safety and Environmental, (HSE), policies, manuals and procedures to agreed quality standards and Clients satisfaction within the specified budget and timeline whilst Contributing to achieving Amec Foster Wheeler’s profitability targets of the project
Responsible for site construction and pre-commissioning activities to ensure that construction and pre-commissioning activities are carried out safely in accordance with the design, drawings and quality plan for the project, and that the completed project meets the requirements of the client, the design, statutory authorities and specific project requirements
Ensure that all legal requirements are adhered to
Implement and direct the overall construction HSE program and ensure strict adherence to statutory health and safety codes
Establish a culture on site where line management, represented by the Area Construction Managers and Construction Supervisors, take direct responsibility for Health and Safety, supported by assigned the HSE
Implement the required Lock-out, Tag-out System for working on energised plant, both during construction and during pre-commissioning
In consultation with Amec Foster Wheeler Home Office, develop and implement a site security and emergency evacuation plan and coordinates the activities with the client, contractors and Amec Foster Wheeler corporate security group
Ensure that contractors implement the Project Industrial Relations Plan, Project Labour Agreement and Project Wage Agreement as appropriate and that labour is treated in a common and consistently fair manner. Coordinate the IR activities with the client, contractors and local community by establishing the required communication forums. Anticipate potential disputes and work stoppages and direct corrective action in terms of the relevant agreements, contracts, regulations and/or Acts
Consult the Project Manager on all major decisions regarding industrial relations, site security, safety and environment
Liaise with local government authorities in consultation with the client
Develop a public and community relations plan in consultation with the client
Maintain client relationship and be the primary contact for client’s communication on the construction site
Ensure Amec Foster Wheeler policies and procedures are fully implemented, and establish field procedures and objectives within corporate policies and procedures as necessitated by conditions at the site in consultation with the Project Manager
Accountable for site establishment including, accommodation, transportation for both on and off site, site offices and furniture, ablutions, communication systems, banking, local suppliers and first aid medical facilities, etc. within the confines of the control budget
Work with Amec Foster Wheeler HR Department to ensure the construction and pre-commissioning management organization is composed of qualified and competent personnel, and ensure effective personnel utilization. Monitor the performance of and supervise the construction management team in the execution of their responsibilities
Review proposed construction and site services contracts before award to determine compatibility with construction requirements, with particular emphasis on construction manpower requirements and plant and equipment
Ensure that the construction and site services contracts are executed strictly in compliance with the relevant terms and conditions and that no unauthorized work is carried out
Conduct constructability reviews to ensure that efficient construction methods are used to build the plant, and monitor these methods with the aim of making them more efficient
Integrate the work of contractors and co-ordinate the operation of the construction site including the coordination of all actions of Amec Foster Wheeler, subcontractors, suppliers, clients and their representatives
Coordinate the establishment of construction schedules, construction method statements, manning charts, material and equipment requirements, construction plant and equipment with the contractors, including the 90-Day Rolling Horizon Look Ahead and ensure implementation and integration with the Project Master Schedule
Responsible for overall construction performance and continuously analyze performance for adherence to quality standards, cost and schedule
Monitor contractors compliance with cost, schedule, quality, environmental and safety objectives and ensure corrective action is taken when non-conformances are detected
Ensure that the Site Quality Management Plan is implemented and maintained
Establish a culture whereby line management, represented by the Area Construction Managers and Construction Supervisors, take direct responsibility for the management of quality supported by the assigned Quality Coordinators
Manage construction support activities including Contract Administration, Cost Control, Site Procurement, Material & Equipment Control, Expediting, Site Administration and construction management staffing, including local employment contracts where appropriate
Implement and maintain an effective Site Materials Control Function, administration of the materials and equipment received on site, warehousing, safe keeping and issuing to contractors
Establish and implement a pre-commissioning and handover plan for the plant including as built drawings and pre-commissioning data as required by the Head Contract
Coordinate demobilization of site contractors and Amec Foster Wheeler including the sale or removal of materials and or equipment surplus to requirements in accordance with a pre agreed procedure
Prepare and submit reports in a timely and professional manner
Accountable for construction management man-hours and other site expenses against the control budget
Prepare construction close out report
Arrange for the packing shipment of all historical information to Amec Foster Wheeler Home Office in consultation with the client
B Tech Degree or National Diploma in an engineering discipline
Registered as a Professional Construction Manager with SACPCMP
At least 15 years hands-on, proven experience in multi-disciplinary construction management, including projects in remote locations and other countries, in particular third world countries
Solid working knowledge of the Guide to the Project Management Body of Knowledge
Extensive knowledge of Health, Safety and Environmental Management principles, practices and statutory requirements
Sound commercial skills and thorough understanding of the various forms of contract, commercial terms and conditions
Sound multi discipline engineering knowledge
Practical multi discipline construction knowledge
Financial management, cost control and forecasting acumen
Good understanding of industrial relations management practices
Thorough knowledge of and hands on experience with, the development, resourcing and monitoring of schedules
Time management skills – ability to effectively manage within tight time frames; managerial, leadership and organizational skills
Highly literate to ensure clear communication, both verbally and written
Thorough knowledge of and hands on experience with computers and associated software packages
Analytical decision making skills
Appreciate and promote team participation behavior within management team
Ability to delegate appropriately without abdicating accountability

109

Construction Manager Resume Examples & Samples

Minimaal 10 jaar ervaring met diverse disciplines van constructie (bij voorkeur in een raffinaderij)
Bekendheid met projectmatig werk en “time management”
Vaardigheid in het aansturen en coachen van een constructie team
Goede kennis Nederlandse en Engelse taal (in woord en geschrift), kennis van de Duitse taal is een pre
Belangrijke competenties: leidinggeven, kwaliteitsgerichtheid, analytisch & probleemoplossend vermogen, communicatieve vaardigheden, impact en overtuigingskracht

110

Construction Manager Resume Examples & Samples

Will be the primary contact with the Project Manager for all Project matters raised in the field
Responsible for the Construction being completed in time, within the established budget and according to safety and quality requirements
To ensure project is performed safely, on time, within budget and meeting all quality requirements
Show high regard for personal safety, safety of personnel & ensure work area is free of hazards
To foster, develop and nurture customer relationships
To provide accurate and timely cost and progress data to manage the project and report to management
To organize, lead, manage, train and coach team members toward professional improvement
To ensure that subcontracts and vendor agreements are developed and performed safely, on time, within budget and meeting all quality requirements
Comply with CB&I’s business and legal policies and protect CB&I from unnecessary risks
Be familiar at all times with contract requirements and ensure that appropriate project team members are informed
Define the scope of work and communicate to team members
Ensure projects are initiated effectively including estimates properly developed, strategy and kick – off meetings held and project procedures and plans completed
Hold effective project planning and co-ordination meetings
Control project documents and ensure they are accurate, complete and comply with project and company requirements
Maintain good written communication through timely and complete project notes, monthly progress report and up-to-date log of project notes
Ensure that change notice and change order procedures are followed in a timely manner
Ensure that all phases of the project are being executed in accordance with client and CBI procedures
Co-operate with all internal and external audits
Assure that CBI Accident Prevention and Safety Procedures are in compliance
Assure that CB&I construction procedures and company policies are being complied with
Comply fully with CB&I Business Conduct and Ethics Policies at all times
Ensure that all contractual obligations are fulfilled in time and to the complete satisfaction of the Client
Actively participate in all safety initiatives
Ensuring that all Construction Supervisors and Superintendents document their day-to-day activities in support of future contractual matters
In absence of the Project Manager in the field, discuss with the Client all Project changes required and, where necessary, provide all information to Project Manager in order to define estimating cost, contract extras and construction delay
Expedite from the Field Project Engineer, and from the other people assigned under his control, all the information requested for a proper handling of Construction Activities
Coordinate completion of construction and testing activities with the start¬-up group when applicable
Responsible for getting the approval of the Client / Project Manager, and requesting Field Changes, before starting modifications of the scope of work
Responsible to implement the project construction execution plans in the field
Bachelor’s Degree in Mechanical Engineering
10 to 15 years’ experience in overseeing tank construction activities and strong knowledge of all aspects of construction
Must have experience in above ground tank construction projects namely floating roof tanks, double deck floating roof tanks, spheres, Elevated water tower etc
Experience on large scale oil / gas and petrochemical capital projects
Display a high regard for safety & quality attributes
Should have strong presentation skills, excellent communication skills
Strategic thinking and leadership with strong abilities in relationship management
Works effectively with peers in a multidisciplinary environment
Energetic with initiative, and strong achievement motivation and techno commercial acumen
Ability to work within a diverse cultural environment
Ability to read, write and speak English, interact with all levels of personnel
Excellent communication, strong selling, negotiation and influencing skills
High standards of integrity and confidentiality
Skilled in MS Office products mainly in Microsoft Excel
Detail focused and good at time management
Previous experience in Kuwait working on projects for KOC and/or KNPC
Experience in remote areas, desert environments and the Middle East

111

Construction Manager Resume Examples & Samples

Educated to degree level (or equivalent) in a relevant subject
Membership of relevant, recognised professional body
Significant relevant achievements with strong, high-level experience / expertise within the Civil Nuclear space
Civil nuclear plant and power plant construction experience
Fluent English with excellent written / verbal communication skills
Other languages such as French, Japanese, Chinese or Arabic would be considered advantageous but not essential

112

Construction Manager Resume Examples & Samples

Using standard guidelines, determines in conjunction with Team Managers or their designees whether to employ in-house construction or an external General Contractor. Determines appropriate staffing of inhouse projects including subcontracting as appropriate. Using standard guidelines, manages construction staffing resources (including trade labor and sub-contractors)
Responsible for all construction aspects of project delivery within approved schedule and estimates. Responsible for construction project file documentation either directly when in-house or via oversight of General Contractor for external projects. Manages subcontracts, material requisitions or change orders.Provides facility content expertise on projects as requested. When requested, ensures policies and procedures are met and manages Superintendent who performs project management tasks
As requested for projects over $5M, provides content expertise to external General Contractors or on backfill activities
Bachelor's degree in construction management, engineering or related field preferred, OR associate's degree and two (2) years of experience in a directly related field
State of California General Contractors License preferred

113

Construction Manager Resume Examples & Samples

Ability to manage multiple projects concurrently. The OSP Construction Manager is responsible for all phases of projects assigned. The project workload will likely include projects in all phases of development and execution
The OSP Construction Manager will monitor all aspects of the project and expedite or escalate as appropriate to achieve the cost, quality and schedule goals for the project. The OSP Construction Manager will make recommendations to management regarding ways to get the project back on track to meet cost, quality and schedule goals if it becomes apparent that any of those goals are not being met
Review and evaluate potential routes to determine least cost and quickest to market solutions. The OSP Construction Manager will summarize potential solutions and make logical recommendations to management
Coordinate with OSP Planning to prepare preliminary cost estimates and route proposals including descriptions of the proposed project and a map showing the preliminary route that is the basis for the estimate
Identification of pole ownership for proposed routes
Knowledge of Design and engineering of final approved projects including final route recommendation, field engineering and pole loading (these function are performed by others however the OSP Construction Manager is responsible for ensuring that the work is started and completed on time and is sufficient to obtain the required permit approvals
Identify and arrange to obtain pole attachment agreements and structure access agreement as need to facilitate cable placement and submit for and obtain pole attachment permits and structure access permits
Identify permit requirements for city, county and state construction permits and submit for and arrange to obtain permits as needed to facilitate cable installation
Read and interpret construction documents, i.e.; prints and plans as well as splicing diagrams that are used in the splicing of fiber optics
Work with company assigned attorneys to obtain required agreements, permits and other authorizations as required to allow cable installation
Monitor FEA vs budgets for project or program
Monitor Variances to authorized FEAs

114

Construction Manager Resume Examples & Samples

Bachelor's Degree with10 years experience in an engineering discipline and/or Construction Management including Brownfields and international projects OR equivalent combination of the experience and training that provides the required knowledge, skills and abilities
A proven track record in project execution and demonstrated commitment to the successful implementation of the project
A proven track record in project development and value generation
Proven ability to lead and motivate diverse cross functional team members from different cultures, think innovatively, execute projects, communicate effectively and deliver results
Proven ability to work with hourly labor, contracted technical experts and construction contractors
Experience in wide variety of projects
Proven ability to work within and understand other cultures, including language skills
Ability to think out of the box, drive-innovation, and hold cross functional teams accountable for results and recommendations that drive critical schedule decisions

115

Construction Manager Resume Examples & Samples

Monitor incoming jobs to create as-built sheet for Construction Manager
Must display ability to read prints and understand SOW
Inputs daily production on Customer and Internal systems
Manages billing for subcontractors
Comfortable dealing with numbers and the processing of financial information
Excellent knowledge of MS Office (Excel and Access)
Results driven and patient
High degree of attention to detail
Organized
Understanding of the importance of deadlines and multitasking to reach goals
Ability to coordinate with others and promote teamwork
Effective communication skills (oral and written)
Ability to recognize problems and reach effective resolution

116

Construction Manager Resume Examples & Samples

Have an understanding of Federal, State, local and company safety policies and assist in the continued development of a Safety Culture in the workplace
Determine resource needs and allocate as necessary to meet project requirements
Resource scheduling to meeting project milestone dates
Interpret and explain project plans and specifications to staff to ensure understanding and compliance with specifications
Direct and supervise internal and subcontracted work force
An understanding of underground utility construction means and methods appropriate to the specifications of the project
Track and report all internal and subcontracted resources and report daily/weekly/monthly production as it relates to the overall project schedule
Prepare and submit budget estimates, progress and cost tracking reports
Requisition supplies and materials, as required by supply chain management, to complete construction projects
Communicate with supervisory personnel, owners, subcontractors and design professionals to discuss and resolve matters such as procedures, complaints and construction challenges
Investigate all construction related claims and delays to ensure proper procedures are being implemented and enacted
10+ years of construction management experience
Ability to use computers for communication, scheduling, budgeting and forecasting
High level of analytical thinking skills to plan and forecast work
Positive history of leadership and communication (written and verbal)
An understanding of utility construction installation methodologies, blue print reading and understanding of requirement/specification technical requirements
An Understanding of critical path methodology to ensure timely delivery of milestone tasks

117

Construction Manager Resume Examples & Samples

Manage, oversee and coordinate the construction methods team of a bid office
Reports to the Bid Manager and coordinates with the Design Manager, Estimation Manager and Commercial Manager of the Bid office
Works closely with the Design Manager to optimize the design for the bid phase, optimizing it with a Value for Money philosophy
Provides the necessary input from the construction point of view to the other Managers
Coordinate with the Construction Services of the Contractor
Prepare internal and external reports pertaining to job status
Civil Engineer
Languages / level: fluent in English
Experience: 10+ years performing functions as Construction Manager, building viaducts or airport projects
Experience in Design&Build projects
International experience will be positively taken into account
Work permit and California Contractor’s License will be positively taken into account

118

Construction Manager Resume Examples & Samples

Understand designs and specifications for the construction of wind farms, including structural, civil and electrical works
Plan, organise, manage and oversee day-to-day construction activities and all other construction management processes, in coordination with Project Management Team and the BOP contractor, to ensure works are completed in accordance with legislative & other authority requirements, project plans and management plans
Prepare and submit daily, weekly and monthly construction reports
Develop detailed construction task schedule to meet the Project Construction Plan and schedule, identifying backlogs, the reasons for them and what is being done to offset them
Be responsible for overall safety enforcement, including review and compilation of documentation and assisting with audits and inspections
Responsible for the management of quality, coordinating and monitoring the progress and quality of work. Review and compilation of documentation and assisting with audits and inspections
Responsible for the management of environment. Review and compilation of documentation and assisting with audits and inspections
Lead regular meetings with contractors and subcontractors
Ensure project documentation requirements are met for handover of projects on completion
Exercise general supervision over professional, technical, and administrative support staff or subcontractors
Review contractor work method statements and specifications to determine appropriate construction methods
Develop and standardise procedures and methods to improve the efficiency and effectiveness of construction process, and monitor workload, administrative and support systems, and internal reporting relationships; identify opportunities for improvement
Train, motivate and evaluate assigned personnel; provide or coordinate staff training; work with employees to correct deficiencies
Confer with supervisory personnel, contractors, and design professionals to discuss and resolve matters such as work procedures, complaints, and construction problems
Promote a positive professional image of ACCIONA with partners, power companies, service providers and other stakeholders and in the business community generally
Deliver effective windfarm projects to a high technical standard and to the agreed program, quality and cost
Assist the Project Manager in the management of local stakeholders including council, landowners and general community
Diligently manage all contractor interfaces and ensure quality and HSE requirements are satisfied
15+ years’ experience in the construction industry including civil, electrical, concrete and crane disciplines, with wind farm experience highly valued
Knowledge and experience in use of engineering standards and industry practices relevant to wind farm construction
Degree qualification with major coursework in civil and/or electrical engineering or a related engineering field; or an appropriate trade qualification with relevant construction industry experience
Demonstrated capacity to work both autonomously and within the team environment; use initiative; solve problems through analytical thinking; & make decisions within an intense construction environment
Demonstrated capacity to influence outcomes
Demonstrated capacity to develop and manage relationships to ensure outcomes are achieved as harmoniously as possible
Possession of a valid driver’s license with a satisfactory driving record
Flexibility to travel as required

119

Construction Manager Resume Examples & Samples

Serving as jobsite representative for the carrier
Assisting in the identification and qualification of the various sub-contractor required for the project, including all site and building trades
Maintaining relationships and acting as the carrier's liaison in matters associated with Federal, State, and Municipal matters, including the City's permitting and inspection requirements
Related bachelor's degree, preferably in Construction Management is a plus
3 years of directly related leadership experience with construction background ,general contractor experience, preferred

120

Construction Manager Resume Examples & Samples

Work in conjunction with the Site Manager to ensure construction is consistently carried out to the highest quality
Review progress on site on a regular basis and oversee/co-ordinate the production and monitoring of programmes
Provide advice, guidance and support to the Project Team, both during the pre-construction and construction phases
Ensure efficient filing and recording systems are in place, and that the records are retained for the appropriate time period
Ensure labour, materials, relevant information and drawings are available in good time, with regular monitoring and control meetings to review
Ensure Customer Journey procedure is followed by the project teams and quality and delivery times are in line with current QR forecast
Review individuals progress against their Action Plan on a regular basis. Ensure the 1:1 process is implemented through your teams
Ensure communication to all team members is clear, regular and consistent
With your Operations Director, plan and allocate appropriate people to each contract in line with prelims
Deputise for the Operations Director when required
If requested, assist in the selection, interview and make recommendations for candidates for employment
Assess and recommend the learning and development needs of production employees
Promote possibilities of repeat work with customer and clients
Represent the business at external and internal functions
Ensure the customer journey process is followed
Promote the ‘Exceeding Expectations’ approach within the business
Work proactively with Sales to deliver our show complexes on time
Produce and circulate Construction Phase Health and Safety Plan. Ensure regular review to maintain adherence to safety procedures
Set the standard, promote best practice and lead the way with safety, ensure compliance
Communicate areas of non compliance or concern
Implement current waste strategy across all developments
Support the Project team in exceeding Considerate Constructor standards
Advise your Operations Director if you become aware of any new activities and provide support where possible

121

Construction Manager Resume Examples & Samples

The day to day line management of the resources with ‘sub’ teams
Daily and weekly productivity of all operations
The management of projects delivered by the team and compliance with the agreed procedures
Collaborate with other Senior Engineers and team managers to optimise the resource and demand balance and ensure adequate and appropriate resources are available to deliver the annual programmes of work
To ensure efficient and effective performance of the team to enable the team to meet performance targets
To ensure schemes are designed and constructed in accordance with design standards
Ensure that Operational staff and Design staff work collaboratively to achieve the outcomes required and that ‘ECI’ activities are completed to ensure efficient and safe delivery
To ensure the elected representatives are kept informed about the progress of works

122

Construction Manager Resume Examples & Samples

10+ years of related experience with electrical field coordination
Safety Focused
Experience in the construction of Pulp and Paper, Power and Manufacturing experience
Ability to use computer programs such as the Microsoft Office Software
Ability to Travel when needed
Prior experience with Managing Contractors
OSHA 30 training preferred

123

Construction Manager Resume Examples & Samples

Pre-construction planning including development of bid packaging strategy, phasing options, contractors' use of site, master schedule logic development, review of preliminary project cost estimates, and constructability review
Coordinate set up project office and staff construction management team
Construction phase responsibilities include planning and chairing pre-construction, pre-installation, and weekly project meetings with Contractor, Owner and Designer
Manage the processing of all construction documents, RFIs Submittals, Change orders, Correspondence, etc
Analyze and recommend objective solutions to project issues
Evaluate contract changes for merit and the ability to negotiate amicable resolution with contractors
Review and evaluate weekly, monthly, and baseline schedules
Experience as the Construction Manager overseeing construction of public works building projects in excess of $10M
BS Degree and 10 years of proven construction experience
Expertise with California building codes, and California seismic and LEED/sustainability requirements a positive
Experience managing a staff of 1-3 individuals
CCM certification preferred
Experience with MEP projects and/or commercial kitchen projects
Experience working on correctional facilities

124

Construction Manager Resume Examples & Samples

Plans and directs tasks necessary for all phases of construction
Set build times on each plan and provide schedules to meet the build times
Ensure that the Construction department is meeting all safety standards in accordance with OSHA and state regulations
Review all architectural plans prior to first time build at each subdivision and final approval on all architectural changes
Visit job sites periodically to spot check quality and policy enforcement
Develop and review performance of all subcontractors
Fifth year college or university program certificate; or seven to ten years related experience and/or training; or equivalent combination of education and experience

125

Construction Manager Resume Examples & Samples

6-10 years of experience as Construction Manager in an Engineering, Environmental or Construction organization required
Oshpd experience
Local jurisdiction experience
Tennant improvement experience
Experience working in an occupied facility
Strong working knowledge of pre-design and pre-construction, building systems/components and technology, contract management, project delivery methods,
Certified Construction Manager (CCM) or CMIT, Professional Engineer (PE) or EIT, or Architect license/certification

126

Construction Manager Resume Examples & Samples

4-year degree in construction-related field (or equivalent construction-related work experience), as well as 15+ years of experience in multidisciplinary self-perform civil contractor
Requires a comprehensive knowledge of construction-related processes, as well as a thorough knowledge of industry practices
Should be able-bodied as the work requires some physical exertion such as long periods of standing; walking over rough, uneven, or rocky surfaces; lifting; recurring bending or similar activities
Maturity in interaction and ability to operate self-sufficiently in the field

127

Construction Manager Resume Examples & Samples

Tailings Rehabilitation
Infrastructure Demolition and disposal
Closing Openings to surface, and remediating Open Pits
4-year degree in construction-related field, as well as 15 to 20 years of experience in field construction is required. Experience in the remediation of large industrial projects at norther locations is preferred

128

Construction Manager Resume Examples & Samples

EHS obligations as Principal Contractor – manage site operations to the defined EHS plans
Day to day operational coordination with key stakeholders
Coordination of trade contractors and specialist consultant site activities,
Coordination of HAZMAT surveys and remediation works by specialist contractors
Review of designs and provision of advice regarding buildability and safety
Site logistics, movements & construction phasing advice

129

Construction Manager Resume Examples & Samples

Ensure Project Manager is updated daily on the status of construction and aware of any issues that will impact project cost, quality or timely completion
Ensure all work is completed in accordance with Crown Castle construction standards, processes, and procedures
Ensure accurate and complete files are maintained for projects and appropriate closeout documents are distributed in a timely manner and are in accordance with corporate and customer standards
Ensure that all jobs are maintained in a project tracking system with complete accuracy
Knowledge of Outside Plant Construction techniques (aerial & underground)
Familiarity with test equipment and techniques for performing RF Sweep test, OTDR, Power Meter and Passive Intermodulation (PIM) testing

130

Construction Manager Resume Examples & Samples

Attend deployment and other customer meetings as subject matter expert for Crown
Develop customer relationships that may result in influencing customers to award service work to Crown
Make regular trips to sites during construction including: bid walk, precon walk, in progress site visits, punch walks and construction closeout. Provide direction to general contractors when doing ground work
Responsible to problem solve issues that may occur onsite and make recommendations based on priority and need to ensure the project and budget are maintained

131

Construction Manager Resume Examples & Samples

Plans and executes construction management responsibilities on projects through all phases of a stage gated project approach
Participate in the engineering deliverables review process, providing applicable comment to such
Prepare or review construction bid packages
Develops a complete understanding of the contract and any relevant subcontracts in order to provide full support to the project management team
Directs execution of all aspects of construction in accordance with the scope of the contracts
Establishes and maintains construction requirements for safety, quality (including inspections), and productivity, along with Bunge compliance protocols
Manages all risks associated with the construction execution of the work--to include being the driver for the focus of on-going risk assessment and associated mitigation efforts related to such
Establishes and defines the construction team organization, staffing requirements, and coordinates staffing with supporting project managers
Hires and manages construction management agents to support construction at sites as needed
Establishes a constructability and operational transition framework to provide quality, value, timeliness, and profitability through all phases of project execution (EPCM, commissioning, startup, and operations as appropriate to the project scope)
Coordinates and/or leads constructability reviews during the stage gated project management cycle
Establishes and maintains operationally consistent work processes that enable work sharing to be effectively executed between multiple offices and construction sites
Understands project controls and finance including scheduling, progress measurement, risk assessment, code of accounts, work breakdown structure, change management, cost control, estimating and planning
Prepare and/or assemble periodic (daily/monthly) project reports and construction activity summaries for the projects under his/her span of control
Model and cascade behaviors supporting BNA capabilities (Operational Excellence, People Management, Business Intelligence, Customer Satisfaction, Value Chain Integration and Risk Management)
Provides strong, effective and decisive CM leadership

132

Construction Manager Resume Examples & Samples

Manages trade partners and consultants; inspects work and approves payment for acceptable work and materials. Manages contract adherence and provides input on subcontractor selection
Manages Assistant Construction Managers; provides training and feedback to foster their growth and advancement
Manages safety for himself/herself; oversees CalAtlantic employees to ensure they work safely; evaluates safety violations and exercises judgment to take appropriate action
Manages work against benchmarks and timetables to ensure that trade partners, employees and vendors perform on schedule and on budget
Exercises discretion to plan and coordinate starts; modifies schedules in response to field conditions to achieve Company goals
Manages the home-building process from permitting to home delivery and first-year warranty
Uses sound judgment to implement CalAtlantic’s jobsite compliance programs and monitors subcontractor compliance with applicable regulations such as building codes, environmental laws, SWIPP, and health and safety programs
Acts as CalAtlantic’s primary representative on the jobsite with third parties such as trade partners, customers and government inspectors and investigators
Manages daily logistics of the site to ensure various contractors work harmoniously; stages the job by determining the timing and location of material deliveries, sequencing of work and option installation, and verifying prior work is completed to CalAltantic’s high standards prior to follow on work
Communicates with sales, purchasing, homeowners, consultants, trades, building officials and customer care to successfully execute the homebuilding process
Strong knowledge of home construction
Knowledge of relevant building codes and all scopes of work
Expertise in BuildPro and Hyphen

133

Construction Manager Resume Examples & Samples

Bachelor’s degree in Mechanical Engineering, Electrical Engineering, Construction Management or equivalent work history with experience in project/program management
3 years of experience in engineering design, construction management, manufacturing, or commissioning
Understanding of electrical engineering best practices including breaker coordination studies, switchgear sequence of operation, NEC code
Ability to define data center system-level architecture, specify/document performance and equipment requirements, create/communicate conceptual designs, and create/maintain project documentation
Ability to produce analyses that ensure designs satisfy defined requirements, including predicted performance and power quality specifications
Possess excellent communication skills, attention to detail, maintain high quality standards
Programming experience with PID loops and past experience with Variable Frequency Drives
Experience in power system reliability and risk assessment studies
Experience with power management and power monitoring systems

134

Construction Manager Resume Examples & Samples

Manages, develops, and coordinates the Arcadis and Client design review process to ensure that plans are within functional program, budgetary, environmental and legal requirements
Manages Hotel and Condominium design efforts through interaction with two Architects, design consultants, and Client personnel from Design Development, through draft to final review, approval of the 100% Construction Documents, through Construction Kick-off and Certificate of Occupancy and turn over of the project to the Client
Oversees the building design process to ensure compliance with standards and guidelines by working with design professionals and various Client stakeholders
Provides Architect(s) with clear and consistent direction with regarding design reviews and constructability review comments
Establishes and follows an effective and efficient design review process to ensure that the design meets the overall goals and objectives for the project, provides maximum value for dollars budgeted, and are appropriate and enduring to meet the functional needs of the Client
Ensures that decisions are made in a timely manner
Ensures that all steps within the project are documented and that the documentation meets legal requirements
Reviews design changes submitted to ensure project remains within budget
Performs others duties as assigned
5-15 years full time paid professional experience construction management of Hospitality, or the planning and coordination of large commercial projects that included the overall design, contract administration, cost estimating, and scheduling activities
5 years of this experience must be with the construction management, design, planning of Hospitality or similar complex, large scale projects
Required Education
Graduation from a recognized college or university with a Bachelor’s degree in Architecture or Engineering
Preferred Licenses and Certificates
A valid Certificate of Registration as an Architect by the California State Architectural Board

135

Construction Manager Resume Examples & Samples

Advance Degree in Engineering or Construction
IFMA, BOMA, r PMP certification
Experience with FAR and DFAR
Working in remote and or overseas locations

136

Construction Manager Resume Examples & Samples

Manages, oversees and coordinates all facets of the construction phase of a college facility project including mobilization, construction, and closeout
Plans, organizes, directs and reports construction management activities and progress to upper management
Coordinates with public agencies during construction to comply with off-site work
Manages both the project budget and schedule to meet the District’s qualitative standards
Performs day-to-day contract administration including assisting the Senior Project Managers in bid analysis, pre-construction meetings and related award coordinating activities
Reviews contractors’ initial construction schedule, submittals, schedule of values, and responds to contractor inquiries
Manages and coordinates project team and contractors in communicating directives and ensuring the project scope is built according to plans, specifications, and cost limits
Reviews submittals from contractors to ensure specification requirements are met
Obtains responses to requests for clarification from contractors and keeps a log of such requests
Negotiates with contractors to achieve a fair and reasonable cost for change orders and reviews their impact on the project
Reviews applications for payment, and performs fiscal management of project resources
Coordinates District delivery of related fixtures, furniture and equipment
Perform other Construction Management functions as assigned
Experience of the design phase of projects and strong design understanding
Experience utilizing Building Information Modeling (BIM)
Experience with Leadership in Energy and Environmental Design (LEED) certified projects and/or the Collaborative for High Performing Schools (CHPS)
Experience with Division of the State Architect (DSA) construction/design processes
A valid Certificate of Registration as a Professional Engineer or licensed Architect in the State of California or
A valid Certified Construction Manager (CCM) credential by the Construction Manager Certification Institute (CMCI)

137

Construction Manager Resume Examples & Samples

Field Construction Manager for natural gas compressor foundation replacement project
Day to day supervision of construction subcontractors
Day to day communications with client
Communication with PM and other AECOM office staff
Ensure construction subcontractor compliance with all client and AECOM requirements
Completion of all required construction documentation
Foundation replacement experience

138

Construction Manager Resume Examples & Samples

Manage the project construction deliverables through effective management of project resources, Sub-Contractors and suppliers to the required quality, time, cost and safety
Establish and control all site based costs, change control, risk management and quality & safety management processes
Manage both internal & external interfaces and build effective relationships with the Customer and Sub-Contractors
Be focal point on behalf of SRA with all contractors for site interface matters
Ensure that senior management is kept informed of project progress and performance via WRSL reporting mechanisms
Ensure that the customer’s requirements are clearly communicated to and understood by the Westinghouse project construction team
Ensure compliance with SRA Site Control and Installation Process CP/E/004
Responsible for ensuring that all equipment is delivered to site in line with installation dates, is fit for purpose, and has proper and complete documentation
Provide support to the Signalling CRE for all CRE and IDC matters relating to construction activities
Organise and plan work to maximise utilisation of resources, ensure task sheets are completed timely and accurately
Ensure that tools and equipment are secure, in a sensible condition and are returned to the controlling organisation when not required
Carry out safety and quality audits on WSL installers and agency / sub contractors
Ensure that the briefing of instructions to staff under his control or allocated to him for such purpose is carried out timely
Responsible for checking and certifying time sheets ensuring correct hour booking and appropriation
Responsible for the timekeeping and discipline of staff under his control
Monitor and control budgets as allocated to him, prepare reports and programmes as required by the Project Manager
Planning day to day work of self and others and accountable for own teams utilisation and reporting
Manage the preparation and submission of tenders and quotations, as directed by the Project Manager from time to time for new works and contract variations, to critical timescales ensuring that documents comply with customer specification and are acceptable to the Company
Attend or arrange appropriate representation at regular meetings with the customer to review progress, performance and value
Hold regular project construction team progress meetings to review site progress and performance
Ensure that the performance of suppliers and Sub-Contractors is monitored by surveillance and inspection and that the contract specification and all relevant standards are implemented in totality
Have overall responsibility for handover of all site works and or services provided by Westinghouse to the client
Ensure that the Plans provided by Sub-Contractors for Quality, Safety & Environment are reviewed for adequacy and that no conflict exists with SRA’s activities
Be responsible for Health & Safety and Environmental management as defined in the Construction Health & Safety Plan and the Environmental Plan
Set up and manage the construction and installation group for the office
Be the focal point for all construction matters for the office
LI-KW

139

Construction Manager Resume Examples & Samples

Have have or had a General Contractors License in one or more states as an RME / RMI
Have 10 years experience in the construction of data/network center facilities and infrastructures
Experienced in using AutoDesks products
Experiences in using construction management applications (i.e. MS Project, Excel, or Primavera
Excellent communication, writing and presentation
Excellent negotiating skills to resolve conflicts, progress complex projects to achieve the clients objects
Self motivating and able to work in remote environments (away from home) for extended periods of time
Responsible for projects in excess of $10 million involving the construction of a technical solution involving IT / Network facility infrastructure (data center, Command centers, (911 Command / Control Center, Telecommunications Systems Installations (Long Haul, Passive Optical, Structured Cabling / Networks, large out-side plant developments, etc.)
Have or have had a General Contractors License in one or more states
10 years experience in the construction of data / network center facilities and infrastructures
Experienced in using AutoDesks products (i.e. AutoCad, Revit, etc.)
Experiences in using construction management applications (i.e. MS Project, Excel, or Primavera)
Responsible for projects in excess of $10 million involving the construction of a technical solution involving a clients IT / Network facility infrastructure (i.e. data center, Command centers, (911 Command / Control Center, Telecommunications Systems Installations (Long Haul, Passive Optical, Structured Cabling / Networks, large out-side cabling plant developments, etc.)
Certified Project Manager (Project Management Institute)
Registered Communications Distribution Designer RCDD – BISCI
Certified Data Center Design Professional (CDCDP) - CNet

140

Construction Manager Resume Examples & Samples

Extensive experience in the construction industry in civils or M&E
Experience of working in the water and waste water industry (preferable)
NVQ/HNC or equivalent minimum, HND or degree qualified in construction engineering preferable
Effective leadership skills
Excellent IT skills – with experience of using powerpoint, excel, outlook and use of the internet
Ability to work well with others and build professional relationships
Good report writing skills
Enjoy working with detail
Systematic approach to problem solving
Responds well under pressure
Focus and energy to deliver accurate work
Good multi tasking skills

141

Construction Manager Resume Examples & Samples

Act as main contractor in the management of schemes where delivery is solely by external subcontractors
Developing a schemes works programme Ensure all weekly and monthly reporting requirements are met by the site management teams and communicated to the relevant Managers
Assisting the commercial team in setting scheme target costs
Help plan for and allocate appropriate supervisory resources as required by the site management team
Holder of a Full UK Drivers Licence
Holds the relevant qualifications: HNC/HND or Degree (Construction related)
High level of knowledge and proven experience in the delivery of projects
High level of ability, advanced knowledge and competence
Capable of dealing with a variety of issues

142

Construction Manager Resume Examples & Samples

Project management of construction oversight contracts
Ability to manage 5-10 construction contracts of varying size and complexity
Run progress meetings, issue agenda and meeting minutes
Proactively review progress and work with contractor to recover schedule or correct deficient work
Assists the Chief Engineer by resolving problems on the job site
Provide leadership to inspectors and guidance on identifying issues and resolving problems
Schedule resources and staff
Issue progressive construction cost and schedule estimates
Review change proposals and work to minimize impact to client
Ensure permitting requirements are met including erosion and sediment control
Perform construction observation field work
Must have the ability to work under conditions that allow for changing priorities and be able to multi-task
Bachelor's Degree in Civil Engineering or Construction Engineering/Management
Preference for Certified Construction Manager and/or Professional Engineer License
Minimum of 5 years of CM experience, 10 years preferred
Must exercise independent judgement and work to achieve generally stated objectives and requirements
Availability to travel 50% of the time with possible overnight stay if assistance needed outside the Atlanta area on other projects
Proficiency with Microsoft applications such as Word, Outlook, and Excel
Must have excellent verbal, written and interpersonal communication skills with the ability to timely communicate project issues to the various project participants
Construction Management and Field experience relating to wastewater collection and conveyance/pumping systems, consent decree programs, water distribution systems. Additional experience with water or wastewater treatment plants is a plus but not a requirement

143

Construction Manager Resume Examples & Samples

Manage a construction management program consisting of multiple, simultaneously occurring constrution projects
Responsibility for managing the project staff, oversight of all construction projects
Oversee the coordination and management of all project related documentation
Interface with Contractors for on-site resolution of construction issues
Coordinate with on-site client representatives and provide updates on the status of the project as well as any issues that require their input to resolve
Responsible for monitoring and reporting on project finances and budgets
Maintain good relationship with client

144

Construction Manager Resume Examples & Samples

Responsible for the overall supervision of construction, industrial, municipal and civil aspects of the project while complying with all the applicable environmental requirements
Manage and work closely with developers, project managers, consultant engineers, utility providers and local authorities to ensure the quality of the project, the completion on time and within budget
Providing the utmost satisfaction to the client in terms of project being completed within the allocated period of time and within the budget that has been assigned, and ensuring the project work will be executed respecting the quality and security standards
Understand best practices of job set-up and management, understand the critical path of decision making
Review weekly job costs and formula project cost projections on bi-weekly basis and approve all subcontractor or material supplier invoices
Provide leadership in scheduled progress meetings
Participate in safety meetings and training
Ensures that the construction work is performed in accordance with the contract documents and to acceptable standards of quality and workmanship including company QC Plan
Ensures work is carried out in accordance with company safety policy including OHSA, Provincial and Federal legislation and union agreements
Review Construction Project contract with client
Optimize opportunities and exhibit good salesmanship to close out change orders, giving constructive information versus combative
Demonstrate the ability to build and manage a cohesive and effective team, with understanding of strengths and weaknesses of team members and using strengths of individuals and group to support the weaknesses
Delegate and monitor work and provide constructive feedback
Able to oversee timely and fair punch list completion, resolve all “routine” change orders, timely delivery through close out submittals, leaving the customer with a positive view of Company
Demonstrable strategic, operational and program management capabilities, with the ability to effectively lead large technically oriented teams
Excellent communication skills (oral, written, presentations)
Exemplary leadership skills, including strong teambuilding capabilities
Strong experience in civil works; the ideal candidate would have experience in waste water treatment plant projects
Bachelor Degree in Civil Engineering, or Structural Engineering or Construction Management
Minimum 7-10 years’ experience as a Construction Manager
Proficient in Microsoft Office Suite, Scheduling Software-MS Project or Primavera
Expert knowledge of and experience in the review and negotiation of technical contracts for large scale heavy civil construction projects, including joint venture (JV) agreements
Strong technical, business, financial and legal acumen

145

Construction Manager Resume Examples & Samples

Perform duties involved with achieving annual revenue/profit goals for construction and engineering operations in a defined geographic region
Manage and assign responsibilities for corrosion engineers, technicians, and construction staff
Oversee application of generally accepted cathodic protection principles for material application, design practices, installation procedures, survey methods, data analysis, and reporting techniques
Develop standard operating procedures for engineering, technician, and construction staff
Analyze engineering, technician, and construction operation's monthly performance, and analyze and control construction material inventory levels
Maintain construction equipment, construction vehicles, and safety equipment
Assist in preparing each year's construction sales budget
Assist in bidding construction projects: read construction plans, conduct material take-offs, labor estimates, and subcontractor requirements
Review construction proposals, contracts, purchase orders, and work authorizations regarding the Company's proposed scope of work, customer expectations, and project objectives
Oversee the assignment of projects to construction staff members to obtain most effective utilization of resources and meet the Company's commitments to customers
Continuously monitor that the most appropriate methods and procedures all taken by engineering and construction personnel to complete the work to meet the requirements established between the Company and the customer
Spot check subordinate's work, as-built drawings; discuss project objectives, and ensure all work meets the Company's minimum performance standards
Analyze the monthly Job Cost Report for individual projects not conforming to job budget goals
Review customer drawings and specifications and determine type and nature of structure involved and physical features of facility
Prepare customer proposals for engineering and construction projects when directly interacting with an individual customer
Approve final pricing for all engineering and construction project proposals prepared by outside sales representatives
Train and develop construction employees consistent with Company policies for job functional tasks
Approve new construction personnel hires, establish appropriate salary adjustments, and assist direct subordinates with employee promotions/terminations
Participate in or direct periodic sales meetings and new product seminars
Bachelor of Science degree in Engineering, Construction Management or related field
10 years of construction experience, Cathodic Protection projects preferred
Able to effectively communicate with both customers and fellow employees
Must be able to travel to customer sites as needed

146

Construction Manager Resume Examples & Samples

Chair and document regular project construction meetings
Record daily log of activities and working trade hours
Coordinate and schedule subcontractor work activities
Troubleshoot unforeseen field conditions to determine cost effective and timely solutions
Set up and maintain field offices/construction trailers
Maintain and update overall project schedules
Work with project managers and superintendents to develop rolling four week look-ahead schedules
Develop “work around” schedules when the proposed logical sequence of events is disrupted
Work with project delivery team and subcontractors to properly administer change work, ensuring that work is not executed until appropriately authorized
Management administration of superintendents
Assist project delivery team in procurement activities
Chair and document constructability reviews
Ensure all employees and subcontractors are adhering to safety policies
Conduct safety audits
Maintain clean, safe and organized job sites
Minimum 15 years experience in field supervisory capacity, preferably in construction industries
4 year degree preferred
Microsoft Excel and Word

147

Construction Manager Resume Examples & Samples

Proven Effective Negotiator
Creativity and design interest
Outstanding interpersonal skills, enthusiasm and energy
Ability to make decisions independently with limited direction
CAD a plus

148

Construction Manager Resume Examples & Samples

May contribute to divisional and departmental strategic planning
May interview, hire, train, mentor, evaluate, and when necessary, terminate operations personnel or make related recommendations
Assimilate, filter and propagate new design/installation/service ideas
Manage the process of receiving documentation, scheduling and conducting sales release meetings
May assist sales personnel with project cost estimates, sales presentations and collections
May assist with the layout and design of the project in accordance with contract documents
Ten years related work experience required
Minimum three years supervisory experience required
Advanced understanding of HVAC, access or other building or electronic control systems
Proficient in Microsoft Office programs including but not limited to, Word, Access and Excel
Strong knowledge of contracting procedures and tactics relative to such areas as project correspondence, documentation, timely notice of claims, subcontract negotiation and subcontract administration
Clear understanding of Revenue, Cost, Gross Margin and Cash Management

149

Construction Manager Resume Examples & Samples

Under direction, provides direction in all conventional and unconventional aspects of construction engineering to manage project construction observation and documentation activities, monitoring contractors' substantial compliance with contract, plans, specifications and special provisions and determining project quality, cost, and adherence to established completion schedule. NOTE: Incumbents do not supervise any contractor's activities and are not responsible for job site safety
Bachelor's degree in construction management, civil engineering, or related field and seven years related experience including personnel supervision. Engineering design experience desirable. With Associate's degree, ten years of related experience. Without a degree, fifteen years related experience is required
Leadership and managerial skills; analytical and organization skills; ability to supervise field representatives and field office personnel

150

Construction Manager Resume Examples & Samples

Interprets architectural, engineering, utility -right-of-way and grid maps, underground utility records, and railroad validation maps and drawings, and makes recommendations for placing system running lines and/or equipment
Understands, participates in and directs the engineering, permitting and construction processes in order to support the requirements of the project contract and coordinates a team effort. Communicates effectively to direct reports the permitting requirements and issues to be resolved
Provides guidance and proper instructions to project personnel for planning, scheduling, and close out of projects. Ensures documentation is properly prepared for subsequent turnover to the owner
Conducts site surveys and threat assessments and generates associated reports, drawings, schedules and cost estimates
Actively participates in scheduling and building access meetings (intra-company) and meetings with municipalities and governmental permitting officials to coordinate and manage the project schedule
Using company accounting techniques, maintains supervision over requisitioning of permanent materials and subcontracting for labor in order to remain within budget constraints, as well as accounting for own and subcontractor’s work at any phase of construction or installation
Understands the policies, procedures, standards, and goals of the organization and directs the execution of all aspects of engineering, permitting, construction, and final acceptance with those in mind
Represents the company in pre-bid, pre-construction and subcontractor negotiations, and is the customer interface on any construction-related meetings or items and any initial permitting contracts
Serves as liaison between project personnel and customer for technical support and Engineering Change Proposals

151

Construction Manager Resume Examples & Samples

4-year college degree, preferably in Construction Management or related field
3-7 years of experience in construction management, preferably in single site/store construction
PMP certification a plus
Experience in petroleum industry a plus
Experience in retail industry a plus
Work closely with the development team to assist with completion of final construction/permit plan sets
Review projects in-depth to develop scopes-of-work, budgets and schedules
Solicit bids from GCs & vendors
Oversee all contractor activity to monitor compliance with building and safety regulations
Meet contractual conditions of performance and demand same of general and sub-contractors
Review work progress on a weekly basis
Prepare internal and external reports pertaining to job status, including budget, schedule and progress
Plan ahead to prevent problems and resolve any emerging ones
Negotiate terms of agreements, obtain permits and licenses as needed
Analyze, manage and mitigate risks
Process change requests and requests for information (RFIs)
Review and approve/deny pay applications
Build and maintain strong relationships with GCs, subcontractors, inspectors and vendors
Work closely with MAPCO’s New Store Opening (NSO) teams
Technical understanding of ALTA surveys, civil engineering and architectural plans
Communication of equipment and plan detail to industry partners
Creation of detailed budgets for new construction and remodel projects and monitor actual costs vs. budget costs for variances
Scheduling projects and keeping them on track
Development of scopes of work with non-technical managers
Ordering furniture, fixtures and equipment (FF&E) as needed for projects
Monitoring all equipment/service orders and compare against invoices and pay apps
Working knowledge of construction contracts and related topics
Working knowledge of public infrastructure & utilities (easements, ROWs, etc.)
Expert knowledge of building products, construction details and rules, regulations and quality standards
Understanding of all phases of construction

152

Construction Manager Resume Examples & Samples

Prepare the Work Forms to be used in correspondence, application for payments, application for inspection of works, material submittals, technical submittals, etc. The contractor shall use such forms in his correspondence with the construction Manager
Monitor supervision consultant for compliance with their contractual responsibilities
Monitor suitability and availability of drawings and other data to ensure the contractor has the right information for the work in hand
Monitor labour levels and suitability of abilities for outstanding work items
Monitor quality of product / information / coordination provided by the consultant
Monitor the quality and timeliness of inspections carried out by the consultant
Ensure the contractor submit shop drawings, product data and samples, and coordinate them with information received from other contractors and transmit to the consultant for review
Monitor contractors for compliance with their contractual responsibilities
Monitor progress of the works for compliance with schedule
Monitor quality of the work installed for compliance with project standards
Ensure that appropriate planning tools are implemented by the contractor, including an accurate two-weeks-look-ahead schedules
Ensure that materials for the works are submitted for approval on time, delivered on time and suitably stored on site prior to incorporation in the works
Ensure that each contractor complies with the current coordinated method statement for coordinating with other contractors
Monitor contractor’s compliance with HSE & security requirements
Report regularly on the compliance of the contractors / consultants’ with all the above items
Assist commercial team to review and certify all applications for payment to the contractor, including final payment, and the consultant shall assist the construction manager in such review to check and certify the acceptance of works
Construction manager together with the consultant shall, within (14) days from receiving the contractor's request, conduct an inspection of the Works or Section and submit a report comprising the result of the inspection to the owner within the said period
The candidate must be skilled in dealing with people with different cultural and behavioural challenges within the various teams and successfully deal with them and yield the best results
Work proactively in a very challenging environment i.e. a demanding client, remote design teams, KSA statutory bodies, mitigating delays in the construction programme, extensive hours needed at times to meet client needs etc

153

Construction Manager Resume Examples & Samples

Overall responsibility for site construction and commissioning activities to ensure that activities are carried out safely in accordance with the design, drawings and quality plan for the project, and completed project meets the agreed scope of work, requirements of the client, design, statutory authorities and specific project requirements
Ensure that all legal requirements are adhered and followed
Establish a culture on site where line management are represented by the Area Construction Managers and Construction Supervisors and direct responsibility for Health and Safety and Environment (HSSE) supported by assigned HSSE Advisors
Implement required Lock-out, Tag-out System for working on energised plant both during construction and commissioning
In consultation with Amec Foster Wheeler Home Office, develop and implement a site security and emergency evacuation plan and coordinates activities with the client, contractors and Amec Foster Wheeler corporate security group
Ensure that contractors implements the Project Industrial Relation Plans, Project Labour Agreement and Project Wage Agreement as appropriate and that labour is treated in a common and consistently fair manner. Coordinate the IR activities with the client, contractors and local community by establishing the required communication forums and anticipate potential disputes, work stoppages and direct corrective action in terms of the relevant agreements, contracts, regulations or acts
Consult the Project Manager on all major decisions regarding industrial relations, site security, health, safety and environment
Development of a public and community relations plan in consultation with the client
Ensure MDM / Amec Foster Wheeler policies and procedures are fully implemented. In consultation with the Project Manager, establish field procedures and objectives within corporate policies and procedures as necessitated by conditions at the site
Accountable for site establishment including accommodation, transportation for both on and site offices, furnitures, ablutions, communication systems, banking, local suppliers and first aid medical facilities, etc. within the confines of the EPC budget
Work with Amec Foster Wheeler HR Department to ensure the construction and commissioning management organization is composed of qualified and competent personnel and ensure effective personnel utilization. Monitor the performance of and supervise the construction management team in the execution of their responsibilities
Review proposed construction and site services contracts before award to determine compatibility with construction requirements, with particular emphasis on construction manpower requirements and plant and equipment etc within the confines of the EPC budget
Ensure that the construction and site services contracts are executed strictly in compliance with the relevant terms and conditions and that no unauthorised work is carried out within the confines of the EPC budget and conduct constructability reviews to ensure that efficient construction methods are used to build the plant, and monitor these methods with the aim of making them more efficient
B Tech Degree or National Diploma in an engineering
Registered as a Professional Construction Manager with SACPCMP or similar
15 years hands-on, proven experience in multi disciplinary construction management, including projects in remote locations and other countries
Working knowledge of Project Management skills
Thorough knowledge of and hands on experience with the development, resourcing and monitoring of schedules
Time management skills and ability to effectively manage tight time frames
Managerial, leadership and organisational skills
Spanish speaking

154

Construction Manager Resume Examples & Samples

Knowledge of construction materials, processes, techniques, and methods
Bachelor’s degree in engineering, construction technology, or construction management
Eight (8) years of related work experience with a broad engineering and/or construction background
Experience in government funded projects in the Middle East and/or underdeveloped countries preferred
An EIT or Professional Certification/Project Management Certification is desired
Additional knowledge/skills may be required by contract or assignment

155

Construction Manager Resume Examples & Samples

Develops, communicates and executes construction project work plans
Develops and manages construction budgets and completes project estimating
Manages project expenses and exercises appropriate cost control
Communicates with the Design Team regarding modifications to the facilities construction, electrical, telecom and data, which will affect moves, adds and changes
Communicates with Properties regarding security issues, maintenance issues, facility renovations, etc
Manages relationships with outside suppliers, such as General Contractors, architects, engineering firms, and suppliers
Demonstrates ability to read blueprints
Demonstrates knowledge of and applies construction industry standards and methods
Remains current on industry advancements and determines relevance to Cerner’s environment
Performs other responsibilities as needed
Works in accordance with corporate and organizational security policies and procedures. Understands personal role in safeguarding corporate and client assets. Takes appropriate action to prevent and report any compromises of security within scope of role
Follows Cerner policies, upholds professional standards, and performs all work in a manner respectful of others
Takes an active part in driving their Professional Development Plan (PDP) and career development
Complete projects on time and under budget
Environments are constructed safely and according to specifications. Achieves competence in and meets the performance standards of the Key Responsibilities
Projects are generally of moderate scope. Projects may vary from managing GC tenant finish to larger scale demo and rebuild or oversight of landlord coordinated services. Multitasking to manage 5-10 diverse projects that may include local, regional, and global site locations at one time
Is able to manage routine responsibilities without direction; receives detailed instructions on new projects or assignments
Is developing expertise in this area, applying standard process information and procedures to resolve a variety of issues
Projects will be of diverse scope with frequent opportunities for independent judgment
Receives general instructions on new assignments, but is capable of managing day-to-day activities independently
Identifies opportunities for process improvement & and suggest changes
Has developed proficiency with AutoCAD and Microsoft Project
Bachelor's Degree in Construction Management or equivalent work experience
5+ years’ construction project management experience
Capital project management /office space experience
Ability to travel to both local and international sites

156

Construction Manager Resume Examples & Samples

Support the project oversight team, provide engineering review and evaluation of technical issues that arise on a daily basis
Provide brief review of related design, construction and quality management questions, e.g. RFIs, DCNs, and NCRs issued by the PPP DBOM project team
When review uncovers non-compliances, questionable documentation, inappropriate judgment or incomplete documentation, assist with and provide more detailed review of the related documentation to assess compliance of contractor's process. Become involved in raising awareness and resolving issues uncovered by the oversight team
Provide and chair weekly forum for internal quality focus group that allows oversight field team members to bring up and discuss project quality management issues and concerns. Primary focus of group is to collectively offer, develop and implement strategies to improve the overall quality management of the project
Attend and participate in biweekly internal Owner project Construction status meetings
Attend and participate monthly internal Owner project Design status meetings
Attend weekly and provide senior review and support to Owner's oversight team at the contractor's weekly Quality Task Force meeting
Help evaluate the contractor's effectiveness in quality management, periodically attend and participate in various contractor quality management meetings, including Readiness Review, Initial Inspections, Completion Inspections, Punchlist Inspections, etc
Perform as lead engineer providing engineering judgment and discernment for daily design and construction issues. As needed, manage involvement from other design and construction oversight staff to assist in reviewing and resolving structural engineering issues that arise
Be available and perform as technical adviser to office and field staff to assist in answering technical design and construction questions and assist in developing strategies to resolve field related construction issues
Use understanding and knowledge of the Design-Build processes, the Project's Concession Agreement and other contract documents to offer discussion points and arguments that defend Owner's best interest
Be the trusted adviser to Owner and the contractor, while being prepared to champion, advocate, support and fight for the level of quality contracted and paid for by the Owner. Ask lots of probing questions of the Contractor
Bachelor's Degree in Construction Management or Civil Engineering is preferred
Licensed as a Professional Engineer (PE) is preferred
At least 5 years of previous construction management experience on highway and/or bridge is required
Demonstrated strong written and oral communication skills is required

157

Construction Manager Resume Examples & Samples

Must be able to take corrective action as necessary
Bachelor’s degree in construction, engineering or heavy industrial experience preferred, or relevant experience
Travel (75% or more) may be required as well as the ability to commit to long-term on site assignments
Coordinates with subcontractors the schedule, safety, cost, and quality decisions in conjunction with the Lead Construction Manager

158

Construction Manager Resume Examples & Samples

Implementation of the Siemens Project Health & Safety Plan, Project Quality Plan and Project Environmental Plan. Assurance that compliance with and briefing of all personnel including all sub contractors
Ensure delivery of the project meets the requirements of the agreed strategies and inform the Projects Manager of any major strategy changes for approval
Production of activity schedules together with resource and cost estimates for all work packages
Accurate reporting of progress to the Project Manager
Ensure timely delivery of all work packages in line with the project programme. Resolution of interface issues to ensure construction, test, commissioning, operations & maintenance and performance schedules will be achieved
Technical responsibility for all Site Engineering works within the Project
Relevant and proven construction experience
Working knowledge of CDM regulations
Good communication skills, both oral and written
Excellent IT skills (specifically MS Office)
The ability to prioritise workload and achieve objectives
A high degree of self-direction
Previous experience of working on rail infrastructure projects involving Civil and Electrification works

159

Construction Manager Resume Examples & Samples

Perform daily inspection and documentation on site and ensuring conformance with contract documents
A minimum of 3 years of construction inspection experience
Knowledge of construction standards, specifications, and methods
Ability to read and interpret construction drawings and associated contract documents
Experience in Microsoft applications, and ProjectWise software
Must have a valid driver’s license and maintain a good driving record

160

Construction Manager Resume Examples & Samples

Conceptual development and budget management of projects and programs (route development, estimate costs, plan projects, schedule projects, and mapping)
Communicate with city, county and state permitting agencies
Work with private property owners such as individuals and railroad companies to secure easements and licenses
Work with telephone companies and private building owners to secure building entrance approval and installation of building entrances
Complete and secure city, state and county permit applications
Complete pole attachment applications and pole line make ready review
Analyze OTDR (Optical Time Domain Reflectometer) test results and coordinate repairs as needed
4-8 years of commercial construction or telecom industry experience required
Intermediate knowledge of permitting, engineering, contractor management, fiber splicing, project management, different types of underground and aerial cable plant installation and maintenance
Intermediate computer skills utilizing: Microsoft Word, Excel, JobTrac, G/Comms, Microstation and/or other CAD/E systems
Valid driver’s license required

161

Construction Manager Resume Examples & Samples

3 years experience as a Construction Manager
Management and supervision experience required
Sprinkler experience is a plus
NICET is a plus
Serves as the primary communication point for all involved in the assigned installation project, e.g., sales personnel, customers, contractors, and installers. Communicates project status on a regular basis. This two-way flow of communication is critical for a smooth and efficient installation
Creates custom system and tracks the assigned installation project from inception to completion
Monitors progress, reports and resolves problems, trends, or conditions that may affect the success of the project installation. Researches and investigates areas that may need improvement or immediate attention. Communicates to the project team what action is needed
Attends meetings and/or conference calls to address any installation issues and gains better understanding of customer preferences
Assists in surveys, special distributions, product returns, change outs, shipping schedules, and contractor invoicing
Prepares electronic project plans that clearly and completely communicates all aspects of the project. Successful project plans contribute to significant reduction in time and materials
Performs other duties as assigned. Offers assistance where needed to maintain efficient work flow
Excellent analytical / problem solving skills
Excellent interpersonal skills to be persuasive and/or assertive when necessary
Sensitivity to the other person’s point of view; to influence behavior or turn a situation around
Overall general company knowledge of products and services
Advanced computer / MS Windows skills, to include software applications such as MS Excel and MS Outlook

162

Construction Manager Resume Examples & Samples

Oversee all construction contracts within area of responsibility, supported by Site Teams at each geographic location or system based area of responsibility
Monitor and oversee construction activities and personnel within the delivery timelines, including development plans and training requirements
Keep Superintendent II and Construction Manager II informed of overall construction activity progress & performance along with monitoring and review of construction key performance indicators
Provide input to constructability reviews and manages the optimum contractor involvement activities
Take reasonable care of your own and others’ health and safety and of those who may be affected in the day-to-day delivery of this role by taking personal responsibility for working to the Wanzek’s Zero Injury principles
Cooperate with all matters relating to health and safety, including following safe working procedures at all times
Act as a role model for Wanzek’s vision and values, behaving in ways that are in alignment with Wanzek’s ways of working while encouraging other to do so as well
Promote equality in the workplace and adopt appropriate behavior when interacting with colleagues
Take necessary care to properly protect the confidentiality, integrity and availability of corporate information from unauthorized disclosure, modification or destruction
Supervise & lead teams
Manage the construction package elements of the procurement process
Monitor contract performance against project milestones, budget and other established metrics
Care for and sustain business relationships with multiple clients
Responsible for Business Development, Estimating, and Construction as well as follow through with existing clients
Bachelor's degree (B. S.) in Construction Management, Engineering or related field equivalent combination of education and experience
Three years of construction industry experience/knowledge of construction techniques, estimating and construction management
Proficient in Microsoft Office Suite including Outlook, Word, Excel, and PowerPoint
Calculate figures and amounts such as discounts, interest, proportions, percentages, area, circumference and volume

163

Construction Manager Resume Examples & Samples

Issues field memoranda or directives to contractors to enforce contract compliance. Advises senior management regarding the necessity for the assessment of liquidated damages and other contractual enforcement mechanisms including default
Uses independent judgment to make on-site change order decisions and has the authority to negotiate with contractors and commit the client’s resources on such change orders
Reviews contractors' claims of disputed work and advises senior management as to appropriate action. Compiles contract and project documentation necessary for adjudicating or denying such claims
Visits various job sites as required in the performance of the above duties
Performs other related tasks
Baccalaureate degree from an accredited college or university
Five years of full time progressively responsible work as a technical specialist in one or more construction and design related fields; two years must involve managing all phases of construction work of a scale and scope similar to the Authority

164

Construction Manager Resume Examples & Samples

Communicate with the Client’s representatives continuously regarding Project Progress and areas
Participate in the planning and formulation of design alternatives and solutions for the construction project; provides conceptual estimates, feasibility studies, and cost estimates, and may coordinate the production of basic design plans and construction documents
Develop and/or administer project budgets and fiscal controls, contracts, and quality control provisions; perform project cost estimating and value engineering, as appropriate
Oversee all aspects of the day-to-day management of the construction project; monitor and coordinate work performed by architectural, engineering, and construction departments
Review and interpret proposed designs, architectural drawings, and building specifications for appropriateness to required function and/or institutional standard, and initiates revisions where appropriate; advise consultants and clients as to how best to achieve required results
Ensure that project operations are in compliance with design specifications and with client requirements
Establish performance and delivery criteria, ensuring that client requirements are being met; prepare project specifications, and coordinates procurement, as appropriate
Authorize the issuance of contracts, purchase orders, and change orders, and approves contractor invoices for payment
Direct work sequencing to expedite project delivery and to minimize disruption of ongoing operations
Inspects, approves, and accepts completed projects for the institution, ensuring conformance with institutional standards, building and life safety codes, and architectural/engineering specifications
Represent the institution in business with customers, consultants, contractors, and other public and/or private agencies and organizations
Researches and prepares various reports pertaining to operations, equipment, policies, procedures, and/or other issues, as appropriate of concerns
A degree in an Engineering is required (Preferable Civil- Western Education)
Post Graduate education such as a MSC or PHD is highly desired
Must have on site Project experience from initial design through to handover and completion
15 or more years’ of working on Multi- Million Dollar projects within the Construction field
Extensive experience working on Healthcare projects (Hospitals 200 Beds +)
Ability to think ahead, identify new opportunities and create new and innovative approaches to work related issues
Strong Management and communication
Demonstrates a determination, desire to succeed and a wish to progress and develop within a commercial role
Excellent working knowledge of Word, Excel and strong user skill level within MS Office or Primavera
Excellent numerical and communication skills

165

Construction Manager Resume Examples & Samples

5-10+ years of related experience in project/construction management
Knowledge of state public works processes
Degree in Architecture, Engineering, or Construction Management or equivalent
Demonstrated experience working independently
Experience in commercial roofing, electrical and mechanical systems
Demonstrated computer software experience related to architecture/construction office environments

166

Construction Manager Resume Examples & Samples

A degree in an Engineering related discipline is required
Must have Healthcare on site Project experience from initial design through to handover and completion
18 or more years’ of experience working on Multi- Million Dollar projects within the Construction field
The candidate should have specific experience in the design, Construction and Management of major tertiary hospital projects of more than 700 Beds
Monitors the operations of all contractors and ensures that all contractors are coordinating at the site level
Provides superintendence of the works
Reviews, monitors and updates the weekly submital schedule report
Verifies the accuracy of all contractors daily, weekly and monthly reporting
Controls and monitors site logistics arrangements, and site security operations
Assist they HSE staff to enforce environmental, health and safety standards at all times
Proactively intervene delay and disruption, provide solutions to site coordination issues, monitor and record delays on deliverables from consultants and contractors
Monitor the performance of the supervision consultant and the compliance of contractors with approved method statements and inspection and test plans
Expedites issue of NOCs and other permits and licenses
Monitors deliveries and storage of equipment and materials on site
Maintains log of all contractors’ (major) equipment on site
Participates in the prequalification and selections of contractors

167

Construction Manager Resume Examples & Samples

Coordinating the work of all site operations
Monitoring of contractors’ progress and preparing progress reports on a monthly basis and assisting in solving any/all deficiencies
Assisting in negotiations with contractors regarding changes in contract value or project duration
Advising the client on cost and time related issues and acceptance of the completed work to the client
Participation and monitoring of the final inspection of works
In collaboration with Human Resources representative, developing, implementing and monitoring personnel administration policies and procedures

168

Construction Manager Resume Examples & Samples

5+ years of experience with managing complex construction projects
Experience in working with senior client leadership, design and construction teams, vendors and sub–contractors, and coordinating medical facility construction with multiple stakeholders
Active Secret clearance required
BS degree in Construction Management, Architecture, or Engineering
Experience with US Army Health Facility Planning Agency, BUMED Facilities Planning, NAVFAC, US Army Corps of Engineers, or installation support activities in coordinating all aspects of construction issues

169

Construction Manager Resume Examples & Samples

Assists primary site project team leader for building construction and renovation projects ranging in value from $500,000 to $100,000,000
Responsible for planning, coordinating and overseeing the work for all subcontractors and self-perform work crews
Ensures that subordinates are trained and knowledgeable of specifications and work procedures, that material is being utilized to ensure optimum efficiency, and that work is being performed in conformance with specified quality requirements
Maintains effective schedule and cost control to ensure the project plan is executed on time and within budget
Plans required work activities to ensure that design drawings, tools, equipment, and materials are available
Monitors the activities of sub-contractors and ensures compliance with project quality, safety, and security requirements
Supervises all construction-related work activities on the project
Plays an active role in the development of the safety culture on the project, making safety a natural part of all work performed. Assists the SSHO in the execution of the project safety plan
Communicates safety policies and procedures to all project personnel, including field staff, subcontractors and self-perform personnel; performs assigned duties in a safe manner and, while supervising others, maintains responsibility for their safe conduct of work and ensures they comply with established safety policies and procedures and practice safe work habits
Controls project change; ensures all changes are properly documented with the Project Manager in accordance with contract requirements
Coordinates the work activities of crafts and functions involved in the project
Schedules work activities and manpower requirements to meet established completion dates, in accordance with the project schedule
Coordinates craft personnel, material, and equipment needed to meet schedules while adhering to budget constraints
Monitors construction activities to ensure work efficiency and that quality and workmanship meet project standards and specifications
Coordinates work activities with the Quality Control Manager to ensure successful execution of the project’s quality plan
Supervises the performance of all field construction activities within a discipline in conformance with plans, specifications, schedules, and cost estimates
Prepares and submits project reports as required
Bachelor’s Degree in Construction Management, Construction Technology, Construction Engineering or related field
CQC Certified
4 year construction management degree

170

Construction Manager Resume Examples & Samples

Manages project indirect overhead budgets
Develops fiscal plans
Responsible for contructability and contruction planning during engineering phase
High School Diploma/GED is required
5-10 years of related experience with 5 years at site manager level required

171

Construction Manager Resume Examples & Samples

Manage site construction activities through issuing and working per construction schedule using MS project or Primavera
Interpret design construction packages and NEC building code
Preparation of Construction submittal packages
Bachelor's degree from an accredited institution or 15 years’ experience in construction management
No relocation is being offered for this role. All candidates must currently reside in the US, and will work out of a US remote office or US Eaton location
BS in Engineering or Construction Management
Knowledge of data center construction
Technical experience in electrical / mechanical/ civil construction techniques
Knowledge and experience with EM385 Army Corp of Engineer requirements
Strong ability to interface with a customer on installation related techniques and building codes
Strong communication and interpersonal skills, with ability to be flexible to adjust to changing priorities in a fast paced work environment
Strong computer skills, including well versed in MS Office Suite of tools
Strong knowledge of Eaton’s electrical product and service offerings/capabilities

172

Construction Manager Resume Examples & Samples

Support other members of the development team
Oversee contractors' work as it relates to budget and schedule activities of consultant team
Inform development group and/or ownership of design and construction status
Review development drawings and documents at all phases

173

Construction Manager Resume Examples & Samples

Supervise and direct all aspects of construction which includes off-sites and on-sites
Responsible for safety and correcting issues as delegated within assigned communities
Insure that the work is in compliance with City or County requirements and building codes
Maintain records of all changes in the community, such as change orders and/or purchase orders
Responsible for inspections and corresponding paperwork
Approve all trade partner’s invoices with regard to work completion and quality
Maintain BuildPro scheduling, ICE report and community center status of closing dates
Coordinate with various managers/departments regarding plans and specifications
Coordinate with Customer Care Representative on quality and walk-through preparation of home sites for move-in
Responsible for the Community and Inventory Homes
Insure timely home completions and deliveries based on posted COE dates
Coordinate with New Home Consultants on delivery schedule
Coordinate compliance with Conditions of Maps and Conditions of Occupancy
Participate in emergency on-call rotation as scheduled

174

Construction Manager Resume Examples & Samples

Schedule and supervise daily trade partner activities in accordance with Buildpro job schedules and business partner signed scopes of work
Plan and schedule all construction activities on homes from start to finish in assigned community
Inspect and ensure that work is in compliance with City/County/State requirements and building codes
Maintain homes under construction in addition to the community itself in a condition presentable to our customers and within the acceptable standards of the company
Provide trade partner feedback to the Area Construction Manager concerning the trade partner’s timeliness and attention to detail
Communicate construction progress and home completion date to the company by accurately updating and submitting the weekly production report
Work closely with the sales, customer care, and management team to ensure open communication on all matters; develop a strong environment conducive to proactive resolution of issues and strong commitment to producing a quality product
Maintain the construction documents (lot files, trade associate files and plan rack) at the job site so that all pertinent information is readily available to management and the other field associates
Conduct pre-construction meeting, if applicable, with customer and oversee the construction, inspection and scheduling of the entire home using inspection forms, plans and procedures
Review and approve start packages prior to beginning construction of homes
Act proactively to resolve homebuyer or homeowner issues
Aid the Customer Care Representative with all outstanding customer care requests to make sure that they are being completed in a timely manner and approved by the customer
Recruit, actively communicate with and train business partners on safety, quality requirements and payment procedures, to assure a solid vendor base
Secure the companies property and protect it from theft, vandalism and damage
Ensure compliance with the company’s safety program
College degree preferred
Minimum of 3 years of experience in a construction related field
Experience with the home building process and practices
Knowledge of building codes, understanding of critical path scheduling methods and safety
Valid driver’s license and a good driving record and valid auto insurance coverage
Working knowledge of new technology such as iPads

175

Construction Manager Resume Examples & Samples

Responsible for safety issues as delegated within assigned communities
Insure that the work is in compliance with city or county requirements and building codes
Maintain records of all changes on the community, such as change orders and/or purchase orders
Approve all trade partner invoices with regard to work completion and quality
Maintain daily log of all occurrences on the community
Coordinate with Purchasing Department regarding budgets and quality of trade partner
Coordinate with customer care representative on quality and walk-through preparation of home-sites for move-in
Insure timely house completions and deliveries

176

Construction Manager Resume Examples & Samples

Provide trade partner feedback to the immediate supervisor concerning the trade partner’s timeliness and attention to detail
Approve all trade partner invoices upon satisfactory completion of the job and approve all deliveries for quantity and condition
Walk assigned homes twice a day
Ensure job site cleanliness and safety compliance as required by State & Federal guidelines
Maintain safety logs and conduct regular safety meetings on-site
Able to manage a high volume of homes
Plan and schedule all construction activities on homes from start to finish

177

Construction Manager Resume Examples & Samples

Attend Construction, monthly and quarterly meetings
Knowledge and use of a wide range of hand and power tools
Excellent problem/conflict resolution skills, ability to handle and diffuse difficult situations and customer concerns in a positive manner

178

Construction Manager Resume Examples & Samples

Must have demonstrated proficiency for all the responsibilities of a Senior Construction Project Engineer
Bachelor’s degree in Construction Management or Engineering or equivalent work experience required
Five (5) years of experience in project management, engineering, or construction is required
Proficient with scheduling software: Microsoft Project, Primavera and/or Suretrak required
Completed OSHA 30 class is required
Experience working for a General Contractor or Major Mechanical Subcontractor preferred
PE, CPM, LEED professional designations is preferred
Advanced knowledge of Microsoft Office Suite - Word, Excel, PowerPoint, and Outlook and required
Basic estimating skills required
RCDD, CPM professional designation is preferred
Proficient with construction financial programs and software preferred
Demonstrates an understanding of accounting and financial management preferred

179

Construction Manager Resume Examples & Samples

Provide site analysis and recommendations to real estate department and site acquisition personnel
Lead due diligence activities, which would include review of surveys, soils and environmental reports
Ensures that the construction assumptions and project risks have been identified and addressed
Select and supervise the design/engineering consultants from initial due diligence through site plan approval and construction
Reviews all drawings and make sure they conform to the company design standards
Develop and prepare project budgets and cost estimates. Ensure that project budget stays within budget
Develop schedules and maintains targeted completion dates. Understands how to manage milestones, and bring appropriate resources to challenges impacting the schedule
Responsible for identifying and assigning General Contractors and negotiates, recommends, and approves contracts with GC’s
Responsible for completion of company construction projects as assigned. Ensure that coordination and regular communication of overall project occurs between design professionals, construction, real estate and others involved in the planning and construction of company projects. Advises management of any project delays or budget challenges and identifies alternate actions to maintain schedules and budgets
Verifies the accuracy of General Contractor's monthly application for payment and provides approval
Monitors all inspections or corrections required by governing agencies
Maintains public relations with neighbors, inspectors, GC's, subs' and trades persons
Coordinates final acceptance, inspection, and scheduling of occupancy
Upon completion of projects, reviews all warranties, O&M manuals, completion of the final punch list required by the contract documents
At least 7-10 years construction management experience in a major chain or multiple location organization for either a General Contractor or Owner's Representative - preferably overseeing ground up big box construction with major site work
Must have demonstrated experience with a full array of heavy construction combined with new and renovation type projects
Must possess strong project accounting skills, including budget development, ongoing project cost monitoring and large money contract management
Must have worked in a major corporate environment
An undergraduate degree from an accredited 4-year university
Excellent negotiation and communication skills
Strong computer skills (MS Suite office of programs including Word, Excel, Access, Project and Primavera-Expedition)
Previous experience in a Project Management role with a General Contractor is a plus
Frequent travel is required**

180

Construction Manager Resume Examples & Samples

Read, understand, interpret, and enforce safety polices and practices
Read and understand plans, specifications and local building codes
Schedules and documents all required inspections, quality testing, or other compliance requirements
Comply with and document environmental permits and inspections
Completes daily reports such as units complete, safety reports, EEO meetings and weekly unit cost worksheets
Read and understand global project schedules and generate two-week construction schedules weekly
Schedule and order materials, inspections and manpower in order to meet project schedules and specifications
Inspects work in progress to ensure that workmanship conforms to specifications and the adherence to construction schedules
Confers with and directs personnel and subcontractors engaged in planning and executing work, interpreting specifications, and coordinating various phases of construction to prevent delays
Maintain a general knowledge of equipment used on the job including basic understanding of equipment limits and designed purposes
Track delivery, use and completion of rentals on the job
Complete regular performance reviews for employees under his/her direction in a complete and timely manner. Ensures the employee understands the review, signs the review form and is provided a copy for his/her records
Confers with personnel to resolve complaints and grievances within work force
Complete 20 hours per year of continued education relating to our field
Attend monthly Superintendent meetings and participate actively

181

Construction Manager Resume Examples & Samples

Coordinate with the Purchasing Department regarding budgets and quality of trade partners
Coordinate with customer care representative on quality and walk-through preparation of the home sites for move-in
Insure timely home completions and deliveries

182

Construction Manager Resume Examples & Samples

Maintain records of all changes on the Community, such as change orders and/or purchase orders
Maintain daily log of all occurrences on the Community
Coordinate with purchasing department regarding budgets and quality of trade partners

183

Construction Manager Resume Examples & Samples

Supervises and directs all aspects of construction which includes off-sites and on-sites
Maintains records of all changes on the community, such as change orders and/or purchase orders
Approves all trade partner invoices with regard to work completion and quality
Maintains daily log of all occurrences on the community
Coordinates with Purchasing Department regarding budgets and quality of trade partners
Coordinates with Customer Care Representative on quality and walk-through preparation of home-sites for move-in
Insures timely house completions and deliveries
Coordinates with New Home Consultants on delivery schedule
Coordinates compliance with Conditions of Maps and Conditions of Occupancy

184

Construction Manager Resume Examples & Samples

Actively support the Company’s commitment to safety and its “Core Values.”
Direct involvement assisting operations and project management in pre job planning of project budgets, schedules, safety plans, quality control plans, staffing plans, and subcontractor selections
Attend bid meetings and walk downs at various client locations to determine scope of work, complexities, accessibilities, and required content of estimates
Assist with the review of RFP instructions, specifications, drawings, technical data, and other associated documents as necessary to schedule, estimate, and support the development of the proposal to the client for the work
Provide oversight and support to payroll, accounts receivable, and accounts payable personnel assigned to the project
Develop construction procedures to meet Division needs. Train employees and Foremen on procedures to enhance efficiencies. Assist Foreman to ensure excellent construction practices are maintained
Conduct daily coordination meetings with subordinates to ensure priorities are clearly understood and adherence to the overall project plan is met
Directly responsible for the coordination of work activities performed by subcontractors and other key vendors
Conduct frequent walk-downs and inspections of the construction area to assist staff members with directing and evaluating work in progress or completed work
Enforce policies and operating procedures within the division in line with corporate policy
Provide guidance and assistance to subordinate managers on operational issues and act as additional point of contact on project related problems
Participate as needed in the resolution of problems on projects or with clients; assist field project personnel in estimating Field Change Orders for assigned projects as required
Perform general administrative, record keeping, and other duties as assigned
5+ years’ field supervisory experience overseeing and directing work of various craft trades, prior experience as a Foreman preferred
Significant experience and knowledge of industrial construction and repair
Thorough understanding of industry practices, codes and standards
Strong communication and interpersonal skills; and good organizational skills
Demonstrated ability to apply innovative and effective management techniques to maximize performance
Ability to analyze project schedules and related reports and provide input towards optimization
Proficient computer skills including Microsoft Word and Excel

185

Construction Manager Resume Examples & Samples

Oversees and monitors all construction activities performed by all of TECHNIP's subcontractors for the project to which he/she is assigned
Implements safety programs and ensures site working conditions by supervising site clean up as required
Coordinates all construction activities to ensure continuous delivery of work with no stoppage or delay
Handles with technical problems or drawings/specifications interpretation in case of need
Revises construction schedule when progress trend is deviating and develops strategies and corrective measures to ensure respect of the revised schedule
Checks and approves subcontractors’ invoices, in collaboration with the Subcontract Administration Manager, Cost Control Manager and Area Construction Superintendents before submitting them to the Site Manager for approval

186

Construction Manager Resume Examples & Samples

Oversee project construction work including construction scheduling (consistent with priorities), material and equipment procurement and coordination, and small system civil, structural, mechanical designs for “field engineered” solutions
Assist in the development and review of construction bid packages for multiple disciplines including: civil, structural, mechanical, electrical, architectural, and insulation
Schedule and coordinate work with production personnel to minimize interruptions to plant operations
Active in the field as a construction manager through ensuring compliance with ADM’s drawings and specifications, and good construction practices
Conduct weekly construction coordination meetings in order to communicate plant events that effect construction work, reinforce various plant policies, and set work schedules for the upcoming weekend and the following week
Monitor resources and materials needed between construction and plant maintenance activities
Support and advise the maintenance department on repair procedures – specifically in the civil, structural, architectural, and mechanical discipline areas
Perform duties in a safe manner, utilizing all approved safety equipment, and successfully completes all safety certification requirements
May perform reasonably similar or related duties as assigned

187

Construction Manager Resume Examples & Samples

Manages Service-Level Agreements with construction vendors and subcontractors
Experience in wireless, telecommunications, construction, and/ or public utility is required
Five to seven or more (5-7+) years of wireless infrastructure or telecommunications building experience
Three or more (3+) years of supervisory or management experience
Must understand quality standards and perform in-process checks
Experience using technology to remotely monitor construction progress
Possess satisfactory written/reading communication skills and be adaptable to changing environments

188

Construction Manager Resume Examples & Samples

Supervises assigned employees, including hiring, evaluating, training, performance management, compensating, motivating, coaching, and developing goals and procedures to ensure the achievement of goals
Develops and maintains a program to accomplish in scope work, including quantifying work set, sizing implementation resources, defining scheduling/optimizing requirements, and developing performance measures, and uses the company’s work management system
Ensures appropriate levels of oversight of contractors working on construction projects
Interacts with external audiences to interpret guidelines and procedures and/or to resolve problems associated with the Company’s programs, systems and services
Meets with state and local officials and customers to coordinate projects, resolve issues and maintain good working relationships
Bachelor’s degree in engineering or a related field is preferred
A minimum of 10 years of experience in construction management or construction project management or related experience is typically required
A minimum of 3 years supervisory/team leadership experience required
Experience in and/or working knowledge of the energy and/or utilities industries preferred
Demonstrated working knowledge of contract administration, federal, state and local underground construction regulations, piping systems design, and installation of gas distribution systems preferred
Demonstrated ability to analyze and interpret data, and to identify relevant issues in solving business problems
Demonstrated ability to present ideas logically and concisely to diverse audiences at all organizational levels, both verbally and in writing
Demonstrated ability to coordinate multiple parties (through direct authority and indirect authority/influence) to the successful completion of projects and to meet expected goals
Demonstrated project management skills, including the ability to coordinate diverse activities, set timelines, budgets and specifications

189

Construction Manager Resume Examples & Samples

Schedule Management
Work experience in China
Strong written and spoken English and Mandarin
Experience in application of Building Information Modeling (BIM) software on projects (Autodesk Revit preferred)
Understanding of Lean Construction or Pull Planning techniques
Construction experience working on high-end retail, hospitality, or similar projects
Ability to travel as needed (50 - 75% of the time) to projects throughout designated region
Bachelor’s degree in engineering, architecture, construction management (or relevant/equivalent experience)
Experience with construction management/project management software (Procore preferred)
Ability to collaborate with drawing production teams to evaluate, identify and solve constructability issues
Effective in a fast paced environment
Analytical in approach when evaluating construction progress or obstacles and provide solutions to stay on schedule and minimize cost impacts
Desire and ability to manage multiple large-scale projects simultaneously
Required communication skills

190

Construction Manager Resume Examples & Samples

Knowledge of German construction practices preferred (particularly Berlin, Hamburg, Frankfurt, and Munich)
Construction experience working on commercial fit-out, high-end retail, hospitality, or similar projects preferred
Confident with making major decisions
Experience in on-site risk-assessment

191

Construction Manager Resume Examples & Samples

Specification/Contract document reviews
Project coordination with Construction Managers and Client Stakeholders
Logistics planning
Field inspection/review of in place work
Compliance review for quality installation
Subject matter expert for concrete placement and field construction activities
Transportation related project experience
Garage construction experience
Tunnel experience

192

Construction Manager Resume Examples & Samples

Provides managerial and technical direction for projects at the client site
Sets example for client-compliant safe work practices and assures that supervised workforce are adequately trained, equipped, and motivated, so that plant projects can be accomplished in a safe, efficient manner
Implements, plans and manages various programs to improve the operation and maintenance of the plant
Reviews all systems and ongoing construction efforts to proactively diagnose and recommend corrective action as needed
Reviews all vital information on goals and production progress
Prepares and maintains a variety of reports, logs, meters, and charts as needed
Communicates regularly by email, standard report, or verbally on conditions, status, progress, and open items

193

Construction Manager Resume Examples & Samples

Accountable for the delivery of the installation project
Accountable for Site Safety
Responsible for securing efficient management of environmental aspects of the installation (waste handling, hazardous material, minization of travel)
Accountable for the financial result of the project (cannot be responsible for costs associated with changes in factory prices or exchange rate variables)
Participates to the sales/installation hand-over and validates the term of the order received from the customer together with the salesperson
Prepares the overall installation program and resource planning
Responsible for planning and organizing the delivery and storage of materials and tools to the site and placing the orders to subcontractors and Non-KONE factory material suppliers
Responsible for site preparations and follow-up of site readiness
Accountable for use of correct KONE installation methods throughout the installation
Ensures cost control as per action plans during budget
Responsible for administrative activities of the project including daily human resource management (absences, time sheet review/approvals) and reports project progress (schedule, installation hours, fitter time sheets, budget and risks) to his superiors
Responsible for maintaining project documentation
Updates information to company management systems
Collaborates with Accounts payable / Controlling to ensure site activities are planned and executed in accordance with contractual payment terms and actual payments received
Accountable for final testing of the equipment and handover to maintenance

194

Construction Manager Resume Examples & Samples

Set and maintain a safety culture in the workplace that establishes safety and compliance as our highest priority
Mentor and lead Solar Installation Team Leads and their teams to insure that our teams provide the highest level of quality and customer satisfaction
Hire, train, promote, discipline, and retain Solar Installers and Electricians
Assist installation teams with any installation or customer issues and provide guidance and direction via telephone and on-site visits
Work closely with resident master electrician and engineering department to ensure that installations are installed in a safe manner and adhering to the National Electric Code
Work closely with office location managers to accomplish office financial goals
Work closely with Project Leads to insure installations are scheduled, completed and inspected as efficiently as possible
Work closely with the Inventory Coordinator to insure that inventory levels are organized and adequate to meet our installation needs
Ensure company vehicles are adequately maintained and resolve any problems that arise with the vehicle fleet of each particular office
Compile statistical data of work in progress and prepare weekly reports for management
Promote and enforce company policies and values

195

Construction Manager Resume Examples & Samples

Develops, manages, monitors, and evaluates best-in-class innovative programs related to specialized knowledge and experience
Utilizes discretion and initiative to ensure services continue to meet and exceed quality and productivity standards
Employs various modes of communication to train all levels of the organization on systems, programs, procedures and processes related to expertise
May select, hire, onboard and train direct reports
May develop and conduct performance evaluations for direct reports
Leads and participates on cross functional teams to share knowledge and expertise to achieve company goals and initiatives
Applies project management skills to effectively manage individual and team projects; uses systems to: create project plans; manage project budgets; execute and achieve deliverables
Works with external vendors to evaluate, negotiate pricing, purchase and implement systems and products
Acts as a resource and partners with all departments and field teams to resolve complex issues related to expertise
Creates and monitors position related metrics that identify trending of key performance indicators
Conducts analysis, interprets reports, and makes recommendations to changes in policies and procedures related to specialty knowledge area
Prepares written and verbal communications using various modes of communication to educate and influence PSC and Field teams
Uses specialized systems to manage work
Provides input to direct report on initiatives that support company goals and objectives
Education Level: Bachelor’s Degree
Relevant advanced education for specialty knowledge areas
Job Related/Industry Experience: 7 years or more

196

Construction Manager Resume Examples & Samples

Monitor construction activities, ensuring the safety of all personnel on site as the top priority
Oversee total field construction effort to ensure project is constructed in accordance with design, budget, safety and schedule requirements
Perform routine quality audits to ensure that work is progressing per the TransCanada specifications and initiate corrective actions where appropriate
Document incidents using the Incident and Issues Tracking (IIT) system and participate in incident investigations
Guide and direct proper project completion, including commissioning, close out of punch list, and training where appropriate
Coordinate and ensure the timely completion of project documentation
Ensure Company environmental policies and safety standards and local regulations are followed by all construction and inspection personnel
Provide leadership for issue resolution during project construction and commissioning phases
Ensure site inspections are carried out in a timely and efficient manner to avoid delays to the construction progress
Review contractors’ request for changes and make recommendations to the Project Manager regarding necessity, effect, cost, and schedule implications
Ensure scope changes are managed in accordance with contract terms and conditions
Monitor construction progress and initiate corrective action when the contractor deviates from project specifications, requirements, or schedule
Address any construction non-conformance issues
Ensure design deviations are properly red lined and drawings are included in the project record file
Coordinate plans with field engineering to overcome any inconsistencies
Provide detailed direction of construction specifications
Collaborate with Company Safety Representatives to promote awareness and understanding of safety performance on projects
Provide construction management support for emergency repair and restoration activities on both oil and natural gas pipeline systems
Knowledge and understanding of construction practices with respect to natural gas / oil pipeline and facility projects
Natural Gas / Oil pipeline and facility construction, commissioning, and operation experience is an asset
Ability to read design drawings to assess construction requirements
Ability to read / interpret (P&ID’s) Piping and Instrumentation Diagrams ensuring quality assurance to construction requirements
Demonstrated leadership skill
Possess a strong background in civil, mechanical and electrical construction
Demonstrated ability to initiate change and help others adapt to a continuously changing environment
Ability to apply business principles to identify and rationalize solutions
Adaptability in a fast paced environment with competing priorities and challenges
The ability to manage both internal and external stakeholder expectations
Computer skills including ability to generate progress reports using Microsoft suite of tools (Outlook, Word, Excel, PowerPoint, Visio, Project, etc.)
Familiarity with TransCanada Operating Procedures (TOPs) that pertain to construction and operating activities
Candidate must be able to work independently with minimal day to day supervision
Candidate must be willing and able to temporarily relocate to assigned project area as required by the project (Special Assignment)
Strong construction supervisory skills
Relevant Technical Trades certification and/or College degree
15 or more years of relevant experience in construction of major capital oil and gas infrastructure projects
5 - 10 years of experience in Natural Gas / Oil pipeline and facility construction inspection and construction preferred
Demonstrated ability to inspect and understand welding processes for API 1104, ASME IV, and other regulatory bodies in support of DOT Sec 192
Understanding of the business setting and a working knowledge of planning and executing construction projects
Familiarity with Operator Qualification Requirements as they pertain to natural gas / oil pipeline and facility construction
Travel regularly to other company locations for temporary assignments, meetings or training which would involve frequent overnight stays away from home
This position will require travel across borders and as such the candidate must be able to provide applicable documentation to this affect

197

Construction Manager Resume Examples & Samples

Provides management and overall leadership for the various CM process including; safety management inspection and testing, resident engineering, submittal review, cost and schedule management, document control. Ensures all personnel are effectively using the Construction Management Information System to log and document all CM activities
Provides on-site responsibility and leadership of the CM safety program
Provides continuous monitoring and updating of the project risk register
Facilitates and documents all weekly construction progress meetings and issues meeting
Establishes assignments for Construction Inspectors, Resident Engineers, Document Control staff and Construction Superintendents for various work areas of the construction operations, monitoring progress and recommends corrective action as necessary
Conducts performance evaluations of assigned staff
Manages the assignment of manpower, materials, and equipment to maximize efficiency, maintain schedules, and to meet budget goals. Keeps alert to possible problem areas and takes preventative action to ensure that critical milestones are met for each phase of the project
Ensures the use of sound construction practices to attain required quality control at the maximum efficiency and minimum cost
Prepares periodic reports summarizing progress of construction activities for higher-level management and clients
Serves as the primary contact with client representatives, subcontractors, and government representatives for construction-related activities. Maintains strong client and community relations
Requires a comprehensive knowledge of construction-related processes, as well as a thorough knowledge of industry practices. Proven leadership and management capability is also required, as well as good written and oral communications skills
Working knowledge of Proliance as Construction Management information system is preferred
Certified Construction Manager (CCM) is a preferred

198

Construction Manager Resume Examples & Samples

Have a minimum qualification BSc, BEng, BA or equivalent
Be a Chartered Engineer
Have more than 20 years’ experience with 7 being similar to this project/role
Experience in managing large infrastructure projects in excess of QAR3 Billion in value
Managing a multi-functional team responsible for delivering a large number of varied infrastructure projects in accordance with the client’s requirements
Managing key stakeholder interfaces which will include all departments within the client organisation as well as other government departments
Overall construction management and control
Monitoring consultants and contracts for compliance with their contractual responsibilities
Monitoring progress of the construction for compliance with schedule
Ensure delivery of projects to time, cost and quality and ensuring highest standards of Health & Safety are achieved
Ensure resources are appropriate to meet current and future commitments and to maximise opportunities

199

Construction Manager Resume Examples & Samples

Schedules and conducts various construction related meetings with Developer, General Contractor and Subcontractors to review site and building plans, specifications, construction schedule, material delivery, inspection issues, critical dates, costs and proposals. These meetings include but are not limited to pre-construction, pre-bid and punch list
Manages and observes work in progress on each project within their respective region to ensure that standard construction practices and procedures are followed and materials used conform to specifications, budgets and schedules. Requires periodic site visits and weekly updates
Review and checks plans and specifications with contractor during construction to ensure compliance with Advance Auto Parts standards and regulations governing construction
Manage, coordinate and communicate with Company's internal resources; Real Estate Managers, Store Planning and Design, Sign Coordinators, Fixture Team, Merchandise Team, Information Technology, Security, Store Operations Team and Construction Field Personnel for timely completion, adhering to scheduled opening, and budget
Maintains weekly reports on construction and inspection activities and compares progress reports
Develops project punch lists for each location
Inspects workmanship of completed installations for conformance to standards, receive certificate of occupancy, punch list completeness follow up and final approval
Review and initial approval of any related invoices, application for payment, change orders, and project close out documents
Must be familiar with various building types and construction techniques
Surveys existing buildings and site, verifies accuracy of building dimensions, identify and locate critical structures & equipment for store fixture / merchandising plans
Assist in the development of a scope of work and budget for projects
Knowledgeable in standard construction costs, forms, and procedures with ability to review and create construction estimates to compare with industry standards
Seeks and submit qualifications for final approval group of qualified contractors, subcontractors, and other related professionals and maintains file project of same group for their respective region
Perform additional duties as may be assigned or required

200

Construction Manager Resume Examples & Samples

Management of the construction management team to achieve the successful execution of the project while ensuring TransCanada's standards of: safety, environment, quality execution of construction specifications, and management of schedule and cost are met
Company representative on site location(s) to administer the construction and ancillary contracts. This includes the review of Contractor's request for changes and recommendations to the Project Manager regarding the necessity, effect, cost, and scheduling implications of said requests for changes
Monitor construction progress and initiate corrective action when the Contractor deviates off schedule
Review and approve the Construction Contractor's progress billing
Coordinate quality inspections in the field to ensure Company specifications, operating procedures (TOPS), and Contractor QA/QC plans are adhered to
Address construction non-conformance issues
Provide expertise for the resolution of concerns that may arise during construction, equipment installation, etc
Participate in the ongoing constructability input into pipeline and facility project design
Responsible, in conjunction with the Project Manager, to ensure site specific documentation is developed in a timely manner
Coordinate on-site training programs related to site specific requirements in conjunction with the Project Manager
Ensure compliance with all ground disturbance regulations along with TransCanada/Provincial/Municipal codes
Coordinate with Field Operations staff to ensure all hot and tie-in work is carried out with a minimum impact to the facilities
Ensure all necessary documentation is in place and enable the Project Manager to acquire the high pressure piping system(s) Leave to Open
Ensure design deviations are properly red lined and drawings are sent to the Project Manager for project as-built updates
Provide feedback to the Project Manager for end of project review with various groups, and attend project close-out meetings
Provide leadership and guidance to construction management team (e.g. inspectors, clerks, etc) including managing daily meetings, and the approval of time and expense items etc
May be involved in one specific inspection discipline, depending upon the availability of inspection staff for the project
Leader in promoting healthy, safe, environmental, and positive attitudes and behaviors
Demonstrate project management skills
Demonstrate working knowledge of construction contractual documents
Sound decision making ability and judgment
Demonstrate exceptional communication skills (verbal/written)
Demonstrate time management and priority setting skills
Exposure to and/or demonstrate leadership skills
Strong skills in forward-looking impact of plans/decisions
Demonstrate problem solving skills
Ability to work independently and/or work collaboratively with members of the inspection team, project management team and senior TransCanada management
Ability and expertise in using MS Office programs, and GPS
Pipeline and/or facilities construction experience working with natural gas facilities and/or oil construction considered an asset
Technical Diploma or related Trade Certification, such as: Survey Technician, Welder, Electrician, Millwright, etc
Willing to complete or have successfully completed the API 1169 pipeline construction inspection certification
High school diploma/GED is required
Experience with in-service facilities such as pipeline integrity programs/maintenance considered an asset
Experience with managing various components of construction projects/programs
A combination of experience and education may be considered
This position requires candidates to
Have and maintain a valid driver’s license
Provide a driver’s abstract for review

201

Construction Manager Resume Examples & Samples

Applies advanced subject matter knowledge to address and resolve complex business issues
As a subject matter expert, contributes to the development of new ideas and methods to improve functional performance
Bachelor’s degree and 5+ years of related experience
Postgraduate coursework is desirable

202

Construction Manager Resume Examples & Samples

Develop the FEL package that provides all front-end planning deliverables to engineering including early detailed construction execution plan that creates the engineering / procurement schedule and sequence
Provide constructability input into the design that optimizes the field construction effort
Responsible for overall management and coordination of construction for the project to maximize productivity and maintain schedule
Develops contingency and recovery plans as required
Monitors equipment performance and utilization; provides continuous improvement input and strategy development
Requires knowledge of construction techniques and equipment in order to develop strategies and manage overall quality and efficiency to ensure daily production
Manages all on-site functions in accordance with the established policies, procedures, systems, and requirements approved by the Company
Develops procedures as needed and functions as liaison between multiple project managers, construction and contractors
15+ years’ experience as a Construction Manager in an industrial construction and/or maintenance organization is required
BS or MS degree is preferred
Excellent oral and written communication skills are required
Professional Engineering certification in related discipline is preferred
Advanced MS Office skills (Word, Excel, PowerPoint) preferred

203

Construction Manager Resume Examples & Samples

Approve all trade partner. Po’s thru Buildpro upon satisfactory completion of the job and approve all deliveries for quantity and condition
Perform documented SWPPPS and safety inspections as required by County, State & Federal guidelines. Maintain accurate records and documentation as required
Conduct 60 day service inspections and complete warranty work
Accountable for communities (home costs) extra costs outside the community budget

204

Construction Manager Resume Examples & Samples

Oversee the scheduling and supervision of daily business partner activities in accordance with job schedule and business partner scopes of work
Analyze proper construction techniques
Maintain all job tasks and order alerts within Build Pro daily
Assure job site cleanliness and safety
Inspect all work daily, using the Lennar Quality by Stage checklist as a guide
Be familiar with each trade partners “scope of work" and assure that properly completed work is certified for payment only
Work together with Regional Operations Center ROC to improve budgets, cost variances, and plan improvements, and systems
Assure that records of all changes on the job, such as engineering reports, change orders and/or purchase orders are properly maintained
Inspect, schedule, and maintain the division’s implementation of the LEMS including the Storm Water, Air Quality, Endangered Species, Environmental Site Assessment and Wetlands modules
Conduct Homebuyer Demonstrations
Ability to understand the manufacturer’s recommendations for use and application of their products

205

Construction Manager Resume Examples & Samples

The Construction Manager is the principal expert on construction and supports the Country Manager through performance of these principal tasks
4-year degree in Civil Engineering or a construction-related field
15 years of construction management experience

206

Construction Manager Resume Examples & Samples

Familiarity with BIM or Virtual Design and Construction
Experience with Lean Construction or Pull Planning techniques
Significant construction experience working on high-end retail, hospitality, or similar projects
Ability to travel as needed (50 - 75% of the time) to projects throughout designated region (North America, Europe, Asia, etc.)
Bachelor’s degree in engineering, architecture, construction management (or equivalent experience)
Experience with construction management/project management software (Procore, Primavera, etc.)
Ability to read architectural and engineering drawings and identify issues
Ability to work independently in a fast paced environment
Ability to “size up” construction progress or obstacles in the moment and provide solutions to stay on schedule and minimize cost impacts
Highly organized with attention to detail
Full understanding of Microsoft Office and MS Project

207

Construction Manager Resume Examples & Samples

Ideally Mechanical Degree qualified but with the correct experience HNC in Mech Engineering would be acceptable (qualifications from other disciplines may be considered)
Minimum of 20 year’s managerial construction experience in the Petrochemical, Gas Transmission and/or Chemical plant field on major projects at home and overseas
Ideally holder of SCO91 National Grid certification
Must Have proven extensive experience of working on National Grid compressor station sites
The Construction Manager should have good communication skills and an ability to lead from the front. Requires a working knowledge of the basic planning principles and a broad knowledge of procedures associated with the site construction work
Aware of working agreements and have the front line contact with local union officials
It is important that the Construction Manager can establish and maintain a working relationship with the client, subcontractors and the home office support departments
Ideally should have a fabrication background with proven experience in the production methods and techniques for shop and site fabrication
Must be experienced in all aspects of shop and site fabrication techniques, and fully conversant with welding specifications, techniques and processes
In depth knowledge and experience with piping design to BS,ASME, ANSI and DIN standards
Must be Able to demonstrate in-depth knowledge and experience with fully welded high pressure pipework within the Oil & Gas industry
Capable of conducting meetings with the site staff and the various subcontractors and be sufficiently articulate to represent the company in regular meetings with the client on all Project matters
A working knowledge of standard contract and subcontract documents is essential

208

Construction Manager Resume Examples & Samples

Must be able to secure and maintain MRPT security certification
Minimum of 8 years progressive experience as a Construction Manager
Experience working for an NGO or other international company is preferred
Must have willingness to travel to Afghanistan field offices

209

Construction Manager Resume Examples & Samples

Manages and coordinates all on-site subcontractor activities for compliance with the CPM schedule and monitors and enforces compliance with subcontract requirements; Implements the Project Construction Execution Plan. Directs staff in the daily, weekly planning process
Directs and approves the development and implementation of subcontractor schedule recovery plans as required
Monitors and approve all DIR replies to the subcontractors
Supervises work of others. Responsible for hiring, discipline, and pay administration of their subordinates. Supervises superintendents

210

Construction Manager Resume Examples & Samples

Conducts self in an appropriate manner as a representative of the transit agency, working effectively in a diverse work environment
Liaises with engineering staff responsible for design on the project and oversees construction activities for contract compliance
Coordinates with local, state, regional, and federal agencies, including the railroads, to ensure compliance with applicable standards
Supervises QC audits
Enforces safety regulations
Participates in negotiations for change orders and contract amendments with the contractor
Monitors contractor activities to ensure that improvements are constructed in accordance with design documents
Monitors contractors' actions to ensure compliance with applicable environmental regulations
Directs the work of field staff
Writes progress and schedule reports used in monthly briefings
Bachelor's of Science in Civil Engineering required, a Master's Degree a plus
At least 15 years experience required on projects with design and construction of major transit improvement projects is required
Past experience with rail projects and heavy construction such as concrete shafts, street work, leak mitigation and track work
NYCT rail project experience is a must
Knowledge in NYCT guidelines is required

211

Construction Manager Resume Examples & Samples

· Conceptual development and budget management of projects and programs (route development, estimate costs, plan projects, schedule projects, and mapping)
· Identify pole ownership, right of way and permit requirements for proposed routes
· Communicate with city, county and state permitting agencies
· Work with private property owners such as individuals and railroad companies to secure easements and licenses
· Work with telephone companies and private building owners to secure building entrance approval and installation of building entrances
· Develop construction bid documents and bid analysis
· Complete and secure city, state and county permit applications
· Complete pole attachment applications and pole line make ready review
· Monitor contractor progress, contractor quality inspection, and timely turnover of assigned projects
· Monitor and ensure SSP (Single Source Provider) on track to meet service level agreements
· Read and interpret construction documents, i.e.; prints and plans as well as splicing diagrams that are used in the splicing of fiber optics
· Review preliminary construction prints from right-of-way authorities and determine potential conflicts; attend utility coordination meetings and construction progress meetings as needed
· Analyze OTDR (Optical Time Domain Reflectometer) test results and coordinate repairs as needed
· Conduct 40% of work in the field and 60% in the office on average; varies per market

212

Construction Manager Resume Examples & Samples

Knowledge of the Manual on Uniform Traffic Control Devices (MUTCD)
Knowledge of soil types throughout the State of New Jersey as it pertains to U-channel direct burial installations
Ability to use mobile mapping applications

213

Construction Manager Resume Examples & Samples

BA or BS, related, or equivalent required
Previous Utility Industry experience is required
Minimum of 20 years previous experience in providing services on major utility construction programs required
Demonstration of leadership skills in managing specialized teams/work groups is required
Ability to mentor and develop team members within a high performance culture required
Process improvement capabilities requiring innovation and ingenuity, providing program management support and interfacing with clients at all levels, including executive level personnel is required
TRAVEL 100% is required
Exceptional communications skills (both verbal and written) are critical

214

Construction Manager Resume Examples & Samples

Handles the day to day tasks on this design-build project in a timely manner
Works closely with the Project Manager
Produces deliverables on time and within budget
Manages the design phase from the 35% (system Confirmation), 50%, 95% and through the 100% construction documents and works collaboratively with all stakeholders
Attends design review meetings and processes Request For Clarification (RFCs) during the design phase
Records design review comments and assures comments are addressed and incorporated into the design documents
Works with the Master Architect to clarify design intent
Provides document control for the project and work closely with the Administrative Assistant
Assists the State in the review and resolution of issues and questions
Works at the site during the construction phase and coordinates work activities with the College and all stakeholders
Attends weekly Progress Meetings. Reports to the State and provides meeting minutes
Tracks and manages all submittals and maintains submittal log
Evaluates, estimates, and analyzes Design-Builder change requests, prepares Potential Change Order files and Change Orders and logs. Manages the process to resolution
Processes all Requests For Clarification during construction, tracks open items and maintains logs on a daily basis
Reviews Design-Builder's baseline schedule and provide comments. Reviews monthly schedule updates and develops independent schedule analyses as needed
Develops the schedule for State furniture and equipment
Coordinates all incoming and outgoing documents as assures documents are received and retained in Document Control
Provides closeout support including receiving as-built documentation, warranties, training, attic stock and other required documentation
Manages the turn-over of all archive documents to the state
Works closely with the Client's Project Manager or representative and builds a trusting relationship
State of California Public Works experience with the Department of General Services
General understanding of building codes

215

Construction Manager Resume Examples & Samples

Ensures that facilities are constructed in accordance with industry codes, permit requirements, safety regulations and engineering design standards
Acts as a Client agent to oversee facility construction projects, including cost estimating, preparing and implementing contracting plans, scheduling crews, procuring bulk material, assisting in obtaining necessary permits, monitoring construction performance and quality, conducting safety meetings, and tracking costs
Works directly with Client management, operations, environmental, engineering, outside agencies and contractors to implement, coordinate and facilitate facility construction work. Provides weekly status update to client
Identifies procurement and construction methods, techniques, efficiencies, and options to ensure that facilities are constructed in a cost-efficient manner and within schedule. Understands budgeting and activity costing strategies
Possesses strong understanding of oilfield operations, engineering, and controls involved in heavy oil treating and gauging, light oil treating, gas processing, casing vapor recovery, steam operations and water treating processes
Organizational and planning skills necessary to manage multiple projects, changing priorities, limited resources, and aggressive schedules

216

Construction Manager Resume Examples & Samples

Start date: 3/15/17
Drug screen / background check required – U.S. Citizenship is required
Travel not required
Temp to hire employment conversion opportunity
4 year accredited degree in construction management, or civil engineering
3-5 years’ minimum practical field experience involving vertical construction in a role of either construction manager, project manager, or project engineer. Additional relative experience may be substituted in lieu of degree
The candidate should be assertive, demonstrate leadership, possess the ability to problem solve; be technically competent in aforementioned responsibilities, be fluent in Microsoft Office applications; and understand the construction management process
Individuals should be highly motivated and possess good written and oral communication skills

217

Construction Manager Resume Examples & Samples

Construction Manager is expected to have 10 years of experience in the management of roadway construction projects with considerable knowledge of roadway, structure, traffic engineering, construction methods, procedures, practices, plans, specifications, and contracts; materials used and performance, environmental, legal, and safety responsibilities related to construction of transportation facilities; No certifications are required for this position
Working knowledge of the VDOT Road and Bridge Specifications, Road and Bridge Standards, Construction Manual, and Inspector Manual; and knowledge in the use of electronic data processing equipment and contract management software. Skill in the use of survey, nuclear density, and materials testing equipment
Ability to supervise and manage employee work groups
Ability to interpret roadway plans, specifications, and contracts
Ability to prepare technical, financial, administrative, and explanatory correspondence

218

Construction Manager Resume Examples & Samples

For all Major Maintenance & other additional works - plan works & produce a quote. When works are awarded - produce a detailed work plan, manage the works (mainly subcontract), ensure records are produced & works are closed out
Liaise with Client
Ensure all works are undertaken with due regard to Safety, quality & the environment
Responsible for all O&M Defects of a more complex nature. These are to be planned, undertaken & records produced so that defects are closed out in a timely manner
Support operational team for repair of significant accident damage
Undertake Temporary Works Coordinator Role for Contract
Ensure production of accurate records are produced for all works & stored in an easily retrievable manner
Provide technical advice to operational teams, sub contractors and Clients
Attend meetings with Clients and Stakeholders and deal with enquiries
Liaise with Client with regard to works in progress and programmed work
Promote contract excellence and best practice, developing innovative use of materials, technology and working methods
Site visits as required to ensure conformity with Quality, Environmental, Health and Safety requirements
Promote and develop teamwork
Develop a good working relationship with our Client
Manage sickness absence within team
Ensure compliance with codes of practice
Manage direct reports & lead team
Any other duties deemed reasonable within responsibility grade

219

Construction Manager Resume Examples & Samples

Interact and collaborate with Leasing Brokers on pre-lease opportunities
Develop accurate cost, assign, execute, and close-out repair and renovation and equipment projects identified through site assessments and notification
Effectively communicate planned work and schedules with Facility Owners, Facility Management and Contractors
Develop outcome based specifications for repair and renovation projects
Complete responsibility to manage repair and renovation work related to building components, MEP, finishes, equipment, signage, and site components
Develop and coordinate scheduled renovation plans and activities
Focus areas of work in contracted facilities will include lighting, flooring, walls, ceilings, roofs, doors, HVAC and plumbing
Identify building and system problems that may be eliminated through improved design or construction practices
Assist in budget development through planned and deferred projects
Build and maintain working partnerships with Facility Owners, Facility Management, Real Estate Community and Contractors, and Corporate Staff
Five or more years professional experience in facilities management, construction management, or property management of commercial buildings
Construction Management degree, commercial real estate project management or related field required
Working knowledge of building components, mechanical, electrical and plumbing systems
Working knowledge of various codes and ADA requirements
Able to manage multiple fast paced projects
Able to build and maintain professional relationships
Sense of urgency utilized to ensure project through-put
Solution oriented
Knowledge of the Commercial Real Estate Industry
Knowledge of construction, design process and project management terminology
Ability to handle multiple tasks and meet deadlines
Must be methodical, analytical and well-organized
Strong communication and verbal presentation skills with project team and client contact a must
Must be innovative, detail-oriented and confident
Must be able to handle stress and customer support issues
Ability to direct vendors and maintain team spirit
Strong leadership abilities
Must possess strong interpersonal and motivational skills
Able to interpret architectural plans and space allocation plans
Space planning, programming and design capabilities
Strong computer aptitude
Working knowledge of

220

Construction Manager Resume Examples & Samples

Field coordination and management of ACC development projects new and existing, as assigned
Serve as a liaison between the General Contractor, Architect, Consultants and Owner
Assist with the management and scheduling of the delivery and installation of FFE
Create and maintain a daily report log of activities
Prepare monthly progress report
Inspect work being performed on a daily basis to ensure compliance with contract documents
Coordinate inspection efforts with all authorities having jurisdiction and consultants
Initial review of monthly pay applications and change orders
Coordinate architect punch list and completion
Bachelors in Business or Construction Management preferred
5 years minimum in Construction Project Management or Field Supervision
Microsoft Suite
Access (preferred)
Construction Scheduling (P6 or Suretrac) and Budgeting Software (Access)

221

Construction Manager Resume Examples & Samples

Acts as first point of contact for Construction Contractor on the Jobsite
Supervises the project Safety officer, QC Inspectors, Turnover Co-Coordinator, Pre-Commissioning Engineer
Ensures quality and safety plans are audited and in accordance with Dow expectation
Monitors site Resources Planning
Follows-up material requirements needs as requested by the Contract Construction Managers and elevates where required
Facilitates work processes for Pre-commissioning, Turnover and Commissioning transition
Coordinates with the projects Turnover Engineer to ensure controlled handover and acceptance of the project
Sign all material and equipment exit passes
Verify that the Contractor maintains the required manpower levels on site and plans for future construction Resources
Conducts Construction Contract final performance evaluation and participates actively in the “Plus & Deltas” project´s exercise
Participate in global networks / meetings
Strong focus on client/project needs and effective interaction with partners

222

Construction Manager Resume Examples & Samples

Be responsible for the administration of construction contracts acting as the Clients Agent or as an EPC/EPCM on behalf of Amec Foster Wheeler. Working across a wide range of projects involving site development both private and public sector, industry, defence, nuclear, remediation, infrastructure and waste sectors
You may be required to manage multiple projects across the UK and manage other members of the team to deliver projects safely, to quality, programme and budget
You will also be required to manage other stakeholders such as contractors, designers and Client organisations
You will be required to act as both the Principal Contractor and Principal Designer on projects with regards to the CDM Regulations and this will include undertaking design and constructability reviews
Able to administer a range of construction contracts such as NEC, JCT and IChemE Red Book
Assess contractor’s competence to deliver work packages with regards to quality, programme, cost and safety
Undertake site safety inspections and ensure actions are implemented to correct issues
Reporting on contractual performance in terms of quality, programme, cost and safety
Communicate commercial / contractual risks, threats and issues within Amec Foster Wheeler and other stakeholders as necessary
Effective team work with members of the Amec Foster Wheeler and Client organisations
The ability to work alone and in with a team to achieve objectives, deliver results and to coordinate resources to meet contract requirements
Effective work planning to ensure projects meet the scheduled targets
The ability to overview situations, review and evaluate, and provide appropriate advice and guidance
Problem solving at both strategic and project levels, working with others to reach a resolution
Support the team in the commercial management of the EPCM/Construction contracts
To report efficiently and effectively on contractual issues having the potential to materially threaten the overall program
To provide both advice and support other teams in terms design, constructability and contractual issues
Actively seek ways to optimise the construction work through innovation and continuous improvement
To demonstrate leadership in fitting with the role within the overall core management team
Be self-motivated in continuing professional development (CPD)
Be effective at planning, monitoring and reviewing
Be decisive and able to work well under pressure
Be good at problem solving
Have a good understanding of health and safety
Possess excellent communication skills both verbal and written
Be able to work as part of a team and on their own initiative
Have skills in developing and managing schedules in Microsoft Project and/or Primavera

223

Construction Manager Resume Examples & Samples

Technically proficient
Good firsthand experience of Construction methodology
Reinforced concrete pours – large volume pours with high strengths (100N/mm2) and high level pumping
Jump form or slip form construction
Large scale projects within larger developments – able to handle logistics and other stakeholders
Supervision of safety on site
Good quality internal and external reporting
Understanding of project costs
Planning and programme monitoring
Decent understanding of contract and commercial management
Able to work in a very small team and to work independently rather than manage others
Sufficiently assertive and confident to chair meetings with the contractor and consultants
Relevant degree from a recognized University or relevant professional qualification
Contracting professional with 10-15 years experience

224

Construction Manager Resume Examples & Samples

Assures a strong “safety base” is incorporated in all aspects of the work
Assures craft employees receive required training and certifications
Performs Condition Assessments and Behavioral Observations of work areas and employees. Corrects noted deficiencies and implements corrective measures
General inspection of the workers and their performance, work plans, and safety
Audit JSA crew meetings
Coordinates work activities with other Discipline Superintendents and Plant Area Coordinators
Responsible for work procedures, scheduling, cost control, project specification conformity, establishment of manpower levels,
Project conformance to national, local and/or company building codes and the maintenance of accurate records
Interprets, organizes, and coordinates work assignments
Oversees and contributes to planning, estimating and field execution
Monitors craft performance relative to budget, schedules and deadlines
Monitors manpower utilization, effectiveness, and productivity
Enforces work rules
Implements day-to-day work assignments through the craft general foreman
Extensive construction and project related experience. Possesses a thorough knowledge of all engineering disciplines, construction technologies and job site management
This is a journey level position and the first level of Construction Management
Oil & Gas Refinery experience
Oil & Gas industry experience in Turnaround or maintenance operations
Previous experience managing of up to 100 direct hire union building trades union craft employees
Demonstrated knowledge of project controls tools – Cost control and reports, change order processes, earned value reporting and evaluation process, productivity measurement
Computer proficient in MS Office
Must demonstrate excellent safety record
This is a senior level construction management position
Process industry experience in Turnaround, construction or maintenance
Management of up to 100 direct hire union building trades union craft employees
Familiar with national labor agreement GPPMA
A minimum of 10-15 years of construction and project related experience

225

Construction Manager Resume Examples & Samples

Manage projects and effectively influence, negotiate, and communicate with internal and external business partners, contractors and vendors
Establish and maintain project schedules and budgets, responsible for overall project delivery including all FF&E and construction
Responsible for on-site supervision during the construction process to include management of General Contractors, and Owner vendors
Participate in the design development process to collaborate across internal stakeholders
Manage and adhere to AIA contract documentation process
Establish effective relationships along with an understanding of municipalities and permit processes
Lead job site meetings, produce minutes and strive for a collaborative team environment
General knowledge of Building Code
Experience building and manage budgets that are several million dollars
Proficient in MS Excel, and MS Project
BA/BS degree from accredited university
Strong communication skills and understanding of the end user
Ability to work within an ambiguous environment and manage change
Self-motivated, able to work both independently and collaboratively within a team as projects dictate.)

226

Construction Manager Resume Examples & Samples

Create and maintain accurate project schedules
Inspects and ensures that work is in compliance with City/County/State requirements and engineered plans and specifications
Visit each development site at least once per day, and be available to resolve any issues that may arise
Able to manage several development projects simultaneously
Plan and schedule all site-related construction activities in communities from start to finish
Conduct pre-construction meeting and final inspections with municipal authorities
Oversee the construction, inspection and scheduling of the entire development project in coordination with the project engineer and senior management

227

Construction Manager Resume Examples & Samples

Oversee and supervise construction projects from conception to completion
Participate in the conceptual development of a construction project and assist with its organization, scheduling, and implementation
Review customer Request for Quotes and project specifications
Assist with drafting proposals and checking cost estimates
Assist with contractor selection
Oversee all onsite and offsite constructions to monitor compliance with construction and safety regulations
Review work progress for multiple sites
Coordinate and supervise subcontractors
Manage third party construction consultants and inspectors
Keep track of contractor cost trends for various US regions
Explain and interpret contracts and technical information to contractors
Review the project in-depth to schedule deliverables and forecast costs
Assist with negotiating terms of agreements and draft contracts
Analyze, manage and mitigate risks including weather and emergencies issues
Ensure quality construction standards and the use of proper construction techniques to meet design requirements
Field experience

228

Construction Manager Resume Examples & Samples

Passion for Design and Real Estate Development
7+ years of experience in construction and/or project management
Ability to effectively manage a full team of consultants and contractors from design through construction completion
Awareness of a variety of concepts, best practices, and procedures of real estate development
Thorough knowledge of architecture, building materials, building codes and construction
Professional and savvy business sense and the ability to interact with multiple stakeholders and pro-actively anticipate their needs
Experience with Budget & Milestone/Schedule Development, Management and Tracking
Bidding General Contractor Services & Hard Bid Analysis, experience and managing the project team selection process and contract negotiation (including GMAX contracts)
Written/Oral communications – ability to speak and write clearly and concisely, get messages across that have the desired effect
Hard worker & Team Player - No task too small. Getting the job done and exceeding client expectations is the key to integrating successfully into our team
Interpersonal Savvy – relates well to others at all levels and uses diplomacy and tact
Self-Starter – able to start and complete projects independently
Technically Savvy: Proficient in MS Office
Develop project budget and schedule and ensure that development and construction activities move according to contract schedule
Review contractor and vendor onsite activities to verify they are in contractual compliance with design specifications, schedules and workmanship standards; Observe and report on construction process and construction related issues
Facilitates the Owner, Architect and Contractor (OAC) meetings and develops effective communications and mechanisms to ensure project coordination with the Owner, Design and Construction participants
Reviews, assesses, and negotiates change order requests with facility design team and contractor
Tracks all changes and identifies the elements of project design and construction
Participates in monthly contractor pay application meetings with Contractor and lender
Provides support on the preparation of monthly lender draws, lien releases and payments to contractors, special inspectors and subcontractors
Interacts with building official inspectors and contractors
Anticipate potential changes to budget or schedule and provide guidance on the review and analysis of changes when presented
Draft, review, communicate and enforce contractual documents for design and construction professionals
Coordinate and direct internal resources (Assistant Project Managers, etc.), as required

229

Construction Manager Resume Examples & Samples

Must be able to perform all the duties required of a Level III Superintendent and Construction Manager II in addition to Construction Manager III duties
Responsible for the overall direction, coordination and evaluation of the project
Oversee construction workers and their supervisors
Coordinate activities of Superintendents, Foremen and/or construction trade workers in one or more occupations, as well as suppliers and subcontractors
Carry out supervisory responsibilities in accordance with the organization's policies and applicable laws
Monitor and direct the progress of the construction site
Ability to negotiate Change Orders
Determine labor requirements for project
Monitor budget project costs to ensure project costs are within budget parameters
Ensure production schedules are maintained to measure time, production and meet requirements of project
Monitor compliance with set regulations
Ability to study project cost indexes and change/adapt to benefit the project
Study, communicate, and improve on productivity analysis provided by Project Manager
Keep records in a systematic, well-organized fashion
Monitor all required paperwork for entire job
Ability to communicate effectively in both oral and written form to large employee groups, owners or engineers
Maintain and enforce discipline throughout the jobsite
Maintain a professional appearance and positive relationships
Interview, hire and train direct reports, plan, assign and direct work, appraise performance reward and discipline employees, address complaints and resolve problems
Ability to organize, instruct and supervise a construction crew in all facets of construction
Ability to estimate
Considerable knowledge of all construction tools, machinery methods and procedures
Must be able to forecast and monitor costs of project
Understanding of construction methods, scheduling and blueprint reading
Ability to demonstrate leadership, motivate workers and communicate with workers and superiors
Computer literate in Microsoft office E-mail, Internet, all Wanzek forms, Excel spread sheets, all documents, photos and field time entry
Ability to work well under pressure and within timelines
Ability to read and interpret documents like safety rules, operating and maintenance instructions and procedure manuals
Ability to calculate figures and to apply concepts of basic algebra and geometry
Ability to interpret an extensive variety of technical instructions in math
Seven years’ experience/knowledge in a supervisory role

230

Construction Manager Resume Examples & Samples

Make regular trips to sites during construction including: bid walk, precon walk, in progress site visits, punchwalk and construction closeout
Understand prevailing rates for all tower and ground work and ensure Crown Castle is receiving competitive rates for quality work
Ensure Project Manager is updated daily on the status of construction and aware of any issues that will impact project cost, quality or completion
Ensure accurate and complete files are maintained for projects and appropriate closeout documents are distributed in a timely manner in accordance with corporate and customer standards
Act as Crown Castle safety observer while at the site ensuring compliance with Crown Castle safety program
Advanced knowledge of budget development and execution
Advanced knowledge of construction management process
Advanced knowledge of site acquisition procedures, including regulatory and permitting process

231

Construction Manager Resume Examples & Samples

Manage own yearly assigned travel budget. Consultant must reconcile expenses on a monthly basis
Proactively work with the mid-scale Development team and ownership prior to taking a deal to Franchise Approval Committee (FAC) to work through scope of work, design issues, and renovation timelines to better improve success rate for FAC approval and License execution for new build and PIP conversions
Act as PIP department first level of appeal to franchisee/owner PIP waiver requests and timeline extension requests. Negotiate PIP issues and work out all PIP project details to set the PIP scope of work and its timeline for completion. Determine when to recommend to the PIP manager to place slow moving projects, or projects that are not otherwise in compliance with their PIP requirements, into PIP default. Work out viable plans and strategies, where possible, to get hotels through the PIP process in a timely manner
Responsible to make sure that all construction/renovation milestones are monitored on a pro-active basis and that information is communicated to the NHOP, Plan Review, Quality and HPS teams to speed openings or enforcement
Consult with franchisees, design professionals and hotel owners to assist in the development of construction schedules for Property Improvement Plan (PIP) and new development hotel projects. Review site plans to ensure compliance with applicable laws, company regulations and brand standards, and comment on required changes or improvements to such plans
Effectively manage an assigned territory by evaluating and tracking progress all ongoing PIP project field activities, prepare written reports and/or summaries for management as needed. Manage the digital library and PIP Tracking (PT) systems for executed projects for content and accuracy of input for assigned projects for both PT and the Digital Library
Periodically perform special Property Improvement Plan inspections both domestically and internationally. Participate in special projects as assigned
Lead the enforcement of mid-scale SRD program compliance
As part of the License Agreement documentation trail, provide timely written follow-up (reports, letters and emails) associated with all site visits and other forms of communication or agreements with Licensee and their assign representatives
Owner Relations – Consultant must develop good franchisee/owner relations offering assistance as needed within reason. Consultant is responsible for addressing design and construction or PIP waiver requests from ownership. Consultant is expected to offer design solutions to problems and be ready to recommend known design professionals to assist franchisee upon request or as Consultant feels necessary
Project size – Typical PIP will cost owner from $500,000 to $5M+ and will involve a 60 to 400 room hotel. Typical New Development will cost an owner $5M to $30M
Demonstrate project management experience in organizing, planning and executing complex, largescale projects from conception through implementation
Demonstrate effective verbal and written communication skills for the purpose of providing information to clients, vendors, senior management and staff
Demonstrated ability to communicate supportive program details (presentation, analysis) to present a persuasive argument or to effectively negotiate a position
Must be able to communicate both orally and in writing with PCs, architects, designers and contractors and clearly explain specific requirements for active projects
Demonstrated ability to write comprehensive, detailed plan reviews explaining Brand standards and Life Safety Requirements as follow up to project submittals
Demonstrate computer skills, with an emphasis on Microsoft Word and Excel
Demonstrate knowledge of brand standards and full understanding of the differences in the various brand standards
Demonstrate a clear understanding of ADA requirements and Company Life Safety Requirements
Must maintain a working knowledge of all requirements described in each brand standards manual
Demonstrate ability to read blueprints including architectural, mechanical, plumbing, sprinkler systems and electrical drawings
Must be capable of writing and typing a comprehensive, technical renovation document (within a specific template) describing the required PIP scope of work that will become part of a franchisee’s License Agreement
Demonstrate ability to remain current with construction trends, code requirements and design through participating in annual continuing education classes
Demonstrate ability to effectively prioritize project details and manage time usage to track active renovation, conversion and new development properties, and to determine if plans have been submitted in a timely manner
Must make immediate time available to return telephone calls and work with franchisees when problems arise regarding project development, Brand standards or vendorrelated issues
Demonstrate knowledge of national building codes, ADA requirements and Life Safety codes

232

Construction Manager Resume Examples & Samples

Excellent organizational and multi-tasking skills
Computer proficiency in Microsoft Projects, Microsoft Office Excel, PowerPoint, Outlook, and Word
Experience in data collection and technical writing
Strong leadership and analytical skill
Ability to read CAD/As-built drawings

233

Construction Manager Resume Examples & Samples

Minimum 12 years construction management experience or craft supervision experience on a similar project
Strong understanding of all construction disciplines
Position requires excellent communications skills and supervisory skills of field construction personnel

234

Construction Manager Resume Examples & Samples

The Site Manager represents the Project Manager on site and therefore has full responsibility for day-to-day site activities
To be responsible for, actively managing, monitoring and reporting on all site based budgetary issues,
Including authorisation of Staff and Contractor timesheets
Assist in the implementation of Zero Harm and supporting initiatives, including site forums, stand-down days and presentations
To be responsible for and ensure compliance with Site Manager’s responsibility and duties as detailed in the Site Management Manual
Maintain and build on existing long-term customer business relationships, ensuring customer needs are fully understood and anticipated across the Siemens EM TS business streams
To carry out staff training, site inductions and ensure compliance with site rules in line with the Site Management Manual
Liaison with field estimating engineers and Energy Management tendering function to ensure sign onto scope, schedule, budget and resource requirements of tenders before submission
Diploma/qualification in management
Diploma or equivalent in Heath Safety, Environmental and Quality management
Formal qualifications to HND/HNC level in Electrical Engineering related subject
Recognised Engineering/Construction related Training & Certification
IOSH certificate managing safety & IOSH certificate in environmental management
NEBOSH general certificate preferred but not essential
Extensive experience in a Site Management role, managing an Electricity Supply Industry construction site
Experience in construction leadership roles
Experienced in all substation site activities including plant, civil, commissioning and health, safety and
Knowledge of environmental legislation and practice
Knowledge of T&D Customer Networks working procedures and authorisations
Engineering awareness – M&E/Civil/Structural
Requires the presence and personal qualities necessary to effectively monitor and control the site – such as people management skills, verbal and written communication skills

235

Construction Manager Resume Examples & Samples

Safety of all personnel working within the construction field operations
Oversee the daily construction operations, including scheduling equipment and manpower, and
Personnel recruitment, selection, training, coaching and retention
Development of budgets and management of the construction operations within the business unit to
High school diploma or general education degree (GED) required; and in excess of five years related
Construction Operations, Materials Operations, Sales, Quality Control, Customer Service/Dispatch, and
Follows policies and procedures; Supports organization's goals and values

236

Construction Manager Resume Examples & Samples

Where FWH has the role of Manager of Construction department, the Construction Manager is appointed by the Divisional Manager and/or Director
Represent FWH on the construction site and organize, administer and control site activities within a defined construction area in accordance with, the relevant legislation, and FWH and Client requirements
Be fully familiarized with the contract requirements, FWH policies and procedures and ensure that those requirements relating to the site operations are implemented on behalf of and under the direction of the Resident Site Manager
Ensure that the FWH Health, Safety, Environment, Security (HSSE) and quality policy is understood and implemented by all supervised staff and construction contractors within a defined construction area
Agree, establish and maintain effective communication and coordination between construction site and home office task force/departments
Promote FWH by demonstrating professionalism and efficiency, establishing credible client and local contact working relationships
Support, promote, and champion the FWH core values throughout the Construction Execution phase
Qualified and registered construction engineer in China
15+ years construction site management experience

237

Construction Manager Resume Examples & Samples

As your knowledge and capabilities increase, you will be able to explore various career paths
Rail and Transit experience
Experience in design documents, AutoCAD, or other form of architectural or engineering drawing production
Experience in electronic documentation control and administration

238

Construction Manager Resume Examples & Samples

Over 10 years’experience in transportation Inspection required
Site Manager certification preferred
Must possess valid driver's license
Ability to lift 50 pounds required
Civil Engineer with Bachelor of Science Degree preferred
INDOT Certified Technician required if without Civil Engineering degree
Considerable knowledge in Microsoft Office programs including Excel, Word, and Outlook required
Willingness to commute to construction projects within Indiana required

239

Construction Manager Resume Examples & Samples

Coordinate project planning, assist in the development of budgets, and review and select consultants, general contractors, subcontractors and suppliers
Project administration, cost control, develop and maintain working relationships with all vendors
Liaison between Construction, Development, QA, and Residential Services Departments
Recommend and develop new systems in order to create efficiency and productivity
Addresses all warranty issues and complete final documentation
Ensures safety compliance on assigned projects and evaluates contractors/subcontractors work to monitor compliance with Company safety programs
Prepare and maintain the RFI, Change Order, Submittal, and Buy-Out logs
Implement and maintain project schedules and quality plan in accordance with established quality guidelines
Examine all construction documents for appropriate construction details and completeness of information, potential design deficiencies, code violations, and constructability
Create and maintain Construction Status Report (CSR) on a monthly basis which provides a cost summary, schedule overview, and forecast where the property will be at completion
Assure applications for payment are being reviewed, approved, processed, and paid
Coordinate and direct estimating, purchasing, engineering, accounting, and construction functions as they relate to the project
Attend regularly scheduled meetings such as Staff meetings, OAC, Subcontractor, safety meetings, and meetings with office personnel assigned to the project
Verify agreements and purchase orders are executed and that all insurance requirements have been satisfied and are in compliance with Company policies prior to subcontractor mobilizing on the project
Bachelor’s degree in architecture, engineering, construction science, or a related field required
7-10 years related experience in the construction industry with a minimum of 5 years management experience multi-family
Knowledge of construction procedures, building codes, construction procedures, estimating, and scheduling practices
Demonstrates consistently positive interpersonal interactions with internal and external partners
Exceptional judgment and decision making skills
Ability to accommodate changing priorities and manage expectations accordingly

240

Construction Manager Resume Examples & Samples

Oversee the daily construction activities at work site
Scheduling of workers, delivery of equipment and materials, and progress of the project
Follows the direction of project manager review and budgets for the project
Interpret business issues and adapts work priorities in own area
Minimum of fifteen (15) years’ experience in construction with an emphasis on the Construction Planning
Preferably a degree in Engineering or Construction Management, or equivalent
Advanced knowledge of CB&I construction planning procedures, progress systems, material management systems, document management and the timekeeping systems
Extensive prior experience on a CB&I construction site, involved with work planning activities including a high level of knowledge and experience with the implementation of detailed work planning processes and procedures

241

Construction Manager Resume Examples & Samples

Manage and direct project teams by providing communication, coordination and follow-up to meet project goals and objectives; ensure project scope or work, schedule and budget are clearly defined and understood
Establish project procedures consistent with contractual documents and quality plans for all engineering work; determine and oversee all project controls, schedules and budgets
Serve as project representative with client, constructor, subcontractors, and vendors at kick-off meetings, job walks, project review, and other meetings and correspondence
Identify and secure necessary approvals for all changes in project scope, budget and/or schedule
Maintain ongoing communication with client, making adjustments as necessary to comply with client needs within contractual obligations, or adjust project deliverables to meet client and Kiewit needs
Ensure all work products are consistent with industry standards and in accordance with good engineering practice and applicable codes, and in compliance with all pertinent legal codes and requirements
Utilize extensive knowledge of basic construction fundamentals and practices to track and budget progress with project milestones
Requires the capability to run large construction projects, including EPC or Design/Build Turnkey projects
Minimum of seven to ten years total experience
Must have a strong knowledge of Construction Management Systems

242

Construction Manager Resume Examples & Samples

Coordinate physical due diligence for the company’s new acquisitions
Create line item budgets and construction timeline for each asset prior to purchase
Create detailed scope documents and manage bidding process
Collect multiple construction bids and review with owners
Review, amend and finalize construction contracts and vendor insurance certs
Create and manage overall project construction plan and scheduling
Manage city design review and permit process
Manage budget and construction loan draws
Manage on-site construction progress and work quality
Manage punch list creation and final work / permit sign-off
Anticipate problems and adjust plan to avoid problems
Create and approve annual capital plan for completed projects
Continual sourcing of new vendor relationships
Continual sourcing of new materials
Development management of smaller new construction projects (50 units)
Hustle - Enjoys the feeling of accomplishing tasks and “getting things done”
Independent - Likes to lead and drive accomplishment in their part of the organization without hand holding
Ownership – accountable to oneself and doesn’t need to be asked to make it happen
Consistent follow-through and ability to juggle multiple projects at a time
High quality standards and pride in getting things done right and on budget
Enjoys being organized and enjoys using software to help in that effort
Enjoys budgeting and using Excel to keep track of budgets
Enjoys planning and using project management software
Ability to control the jobsite and manage subcontractors
Able to communicate regularly and professionally with owners and partners

243

Construction Manager Resume Examples & Samples

Responsible and accountable for all construction activity that occurs on project site, including but not limited to: safety, quality, project controls, materials, subcontractors, contract execution, client interfaces, client relations, engineering interfaces and start-up/commissioning interfaces
Direct, coordinate and supervise on-site discipline superintendents, scheduling, engineering, cost control, material control, commercial management, and administrative staff
Responsible for the overall project safety and compliance with the applicable Safety and Health Plans. This includes, reviewing and auditing site specific safety documentation for Pre-Task Analysis (PTAs) and Task Safety Observations (TSOs) on a regular basis
Supervise and direct overall construction effort to verify project is sequenced and constructed in accordance with design, budget and schedule requirements
Responsible for efficient use of materials and equipment, and contractual performance of Subcontractors and Company personnel
Enforce compliance with project procedures, safety program requirements, work rules and client requirements. Document all violations, notify project management, and recommend/implement corrective actions as required. Provide accurate performance feedback for all project team members
Develop and foster effective client and subcontractor relationships. Interface with client representatives, municipal authorities and other contractors as necessary to execute projects
Coordinate and communicate with the Engineering Manager and Discipline Engineers to plan and sequence engineering deliverables and resolve field engineering items
Collaborate with the project management team to develop and implement Project Execution Plans, project procedures, working documents, site procedures and project standards
Authorize purchase requisitions for field procurements; Review and approve subcontractor progress payments and Supplier invoices
Read, interpret, and understand civil, structural, mechanical, electrical, controls and instrumentation drawings, specification and commercial documents
Provide technical assistance, interpretation of drawings, and recommendation of construction methods and equipment installation
Complete daily, weekly and monthly progress reports in addition to other reports as necessary to document construction progress. Review all subordinate and subcontractor field reports
Assess future work activities and identify any concerns with work plans by utilizing 3-week look-ahead reports and the overall project schedule
Oversee and direct construction progress tracking and forecasting including Field Progress Measurement Systems, Critical Path Scheduling and commodity tracking systems
Oversee and direct the final construction documentation turnover process to clients. This includes construction turnover to clients or internal startup and commissioning teams
Provide site oversight and coordination of startup and commissioning teams

244

Construction Manager Resume Examples & Samples

Establish and implement construction schedules, methods, manning chart, material and equipment requirements
Control all jobsite expenditures for labor equipment, material and services and ensure that field operations are within the budget
Be responsible for overall project performance and continuously analyze performances for adherence to quality standards and schedules
Plan and establish procedures in order to ensure that all construction operations meet engineering designs and specifications as well as ensure that corporate policies and procedures all fully implemented
Establish project field procedures and objectives within corporate policies as necessitated by conditions at jobsite
Maintain client relationships, and act as primary contact for clients communication with the field activities
Direct the development and implementation of a training program for subordinate personnel as well as the overall project safety programs and ensure strict adherence to federal and national safety codes
Establish ad manage the site construction management organization and provide leadership in the performance of all activities related to execution of the construction work, covering constracts administration, quality control, planning and cost control, material management, office management, labour relations, HSE and accident prevention
Bachelor’s degree in Construction engineering
At least 20 years of experience in heavy civil construction project
Experience with construction environment, an asset
Demonstrated talent for team work
Proven problem solving abilities
Dynamic approach and organizational skills

245

Construction Manager Resume Examples & Samples

Graduate Mechanical / Civil Engineer
Overall 16+ years of experience in Construction supervision, of which 7+ years should be for the large scale industrial / Oil & Gas / Petrochemical projects. Experience in construction of Oleo-chemical Industry shall be added advantage
Knowledge on Large Equipment erection, Boiler erection, Piping, electrical system, Instrumentation system, Firefighting, HVAC system
Knowledge of Local regulations for the Industrial Projects
Strong interpersonal skills with experience in dispute prevention, claim assessment & evaluation
Ability to communicate effectively, to different level of management and diverse ethnicity
Fluent in English, written & verbal as the project language shall be in English
Fluent in local language, written & verbal – Bahasa Indonesia
Duration of this assignment shall be with a duration of 1 year

246

Construction Manager Resume Examples & Samples

Bachelor’s degree in Construction Management, Mechanical or Electrical Engineering with experience in construction/program management for mission critical facilities
Familiarity with electrical engineering best practices including breaker coordination studies, switchgear sequence of operation, NEC code
Possess excellent communication skills, attention to detail, and be able to maintain high quality standards
Experience directly related to the design or construction of data centers

247

Construction Manager Resume Examples & Samples

Performs quality assurance and contract administration for large, complex construction projects at Ft. Rucker, AL
Works under supervision of the Ft. Rucker Resident Engineer, who assigns responsibilities and delegates authority to make determinations and decisions, e.g., construction progress and pay entitlement, QA and other contract compliance
Administers on-site safety standards compliance
Resolves unsafe work conditions and practices
Administers the Accident Prevention Plan
Prepares construction modification documents to include sketches and cost estimates
Evaluates impact of modification to schedule
Gathers and evaluates field data
Prepares modifications package for supervisor’s review
Negotiates contract changes within funding limitations
Prepares progress reports
Reviews schedules, shop drawings, submittals and contractor quality control reports
Compare data to project documents for consistency
Initiates corrective action as required
Evaluates contractor’s progress reports for consistency with project progress, material quantities and storage, and man-hours
Prepares and coordinates contractor payment documents utilizing progress reports
Reports and records significant job progress, critical issues and potential problems
Ensures corrective measures are applied in the field of by elevating problems to appropriate level
Independently inspects construction work and incoming materials and equipment to determine compliance with contract documents and schedule
Prepares and transfers contract revisions, material submittals, and as-built information
Reviews submittals and maintains submittal registry
Conducts labor interviews with contractor personnel
Checks interview data against payrolls
Enforces compliance with applicable laws
12+ years of experience
Experience managing large, complex military construction projects

248

Construction Manager Resume Examples & Samples

Both the delivery team and Operations / Project Manager / Director about programming, resourcing and safe working practices in delivery of the project
The Commercial function to monitor and review the preliminary project costs against actual costs and delivery
The Planning function to monitor and review progress against agreed timetable
26 days annual leave + 8 bank holidayswith the opportunity to buy more holidays once you have been with a for a short while
BUPA Healthcare Insurance (single cover with option to 'trade up' to cover your family
Carillion 'Thank You' Scheme, which offers flexible, tax efficient benefits such as child care vouchers, cycle to work scheme & discounts on high street brands

249

Construction Manager Resume Examples & Samples

Works closely with regional leadership teams to develop residential budgets and allocate funding for new builds, rebuilds, upgrades, and other construction efforts
Ensures regions have appropriate engineering/design and construction resources to achieve all Division financial and business objectives
Provides subject matter guidance to employees and contributes to the development of the organizational business strategy
Manage the relationship with one or more of the strategic suppliers; e.g. Tier 1 and Tier 2 providers; for infrastructure and application services
Implement processes and organizational capability to execute supplier contract and relationship management
Monitor strategic supplier's performance. Manage, with suppliers, design and administer Comcast surveys and other feedback processes
Monitor and improve the quality of the relationship between Comcast and the supplier
Ensure supplier and Comcast are in compliance with contract terms and conditions, commitments, and notifications
Interacts with strategic supplier to ensure that daily operations meet contractual obligations and outcomes
Manage supplier performance audits (regulatory, technical, security, risk, etc.) for the supplier and provide feedback to Comcast leadership team on performance
Provide feedback to the supplier on supplier performances and ensure resolution of escalated issues with the supplier
May be responsible for creating vision, clear direction, and strategy for teams. May establish, manage and coach team to clear objectives and performance expectations

250

Construction Manager Resume Examples & Samples

Upon award of the work, the CM will work with engineering to develop execution strategies and detailed plans to safely and efficiently execute the work in meeting client, business and project objectives
Pre-construction services include developing a logical work sequence, procurement and subcontract plans that supports construction need dates
The CM must possess leadership and management qualities as both are required to successfully deliver projects
As a leader the CM must have effective communication skills to build consensus with project team members and stakeholders
The CM directs his staff and contractors on project objectives and manages the work through others to ensure objectives are met
The CM must have a solid safety implementation experience and successful safety performance record. Familiarity with OSHA requirements is a must
The CM is required to implement a comprehensive safety process on the job site utilizing Jacobs HSE SOPS. Achieving Zero Incident performance is an expectation
Manages project indirect overhead budgets. Develops fiscal plans. Monitors performance and utilization. Functions as liaison between engineering and construction
8-12 years of related experience with 5 years experience at site manager level
BS/MS in Construction Management or Architectural / Engineering Discipline is preferred
Local candidates preferred, no relocation or per diem offered

Download Construction Manager Resume Sample as Image file

Related Job Titles

Construction Superintendent Resume Sample

Plant Manager Resume Sample

Construction Administrative Assistant Resume Sample

Architecture Manager Resume Sample

Construction Site Manager Resume Sample

Project Construction Manager Resume Sample

Construction Foreman Resume Sample

Construction Services Resume Sample

Construction Intern Resume Sample

Construction Project Resume Sample

Construction Assistant Resume Sample

Manager Plant Resume Sample

Browse More

Construction Manager Resume Samples

The Guide To Resume Tailoring

Craft your perfect resume by picking job responsibilities written by professional recruiters

Pick from the thousands of curated job responsibilities used by the leading companies

Tailor your resume & cover letter with wording that best fits for each job you apply

Resume Builder

Resume Builder

15 Construction Manager resume templates

Read our complete resume writing guides

How to Tailor Your Resume

How to Make a Resume

How to Mention Achievements

Work Experience in Resume

50+ Skills to Put on a Resume

How and Why Put Hobbies

Top 22 Fonts for Your Resume

50 Best Resume Tips

200+ Action Words to Use

Internship Resume

Killer Resume Summary

Write a Resume Objective

What to Put on a Resume

How Long Should a Resume Be

The Best Resume Format

How to List Education

CV vs. Resume: The Difference

Include Contact Information

Resume Format PDF vs Word

How to Write a Student Resume

Construction Manager Resume Examples & Samples

Construction Manager Resume Examples & Samples

Construction Manager Resume Examples & Samples

Construction Manager Resume Examples & Samples

Construction Manager Resume Examples & Samples

Construction Manager Resume Examples & Samples

Construction Manager Resume Examples & Samples

Construction Manager Resume Examples & Samples

Construction Manager Resume Examples & Samples

Construction Manager Resume Examples & Samples

Construction Manager Resume Examples & Samples

Construction Manager Resume Examples & Samples

Construction Manager Resume Examples & Samples

Construction Manager Resume Examples & Samples

Construction Manager Resume Examples & Samples

Construction Manager Resume Examples & Samples

Construction Manager Resume Examples & Samples

Construction Manager Resume Examples & Samples

Construction Manager Resume Examples & Samples

Construction Manager Resume Examples & Samples

Construction Manager Resume Examples & Samples

Construction Manager Resume Examples & Samples

Construction Manager Resume Examples & Samples

Construction Manager Resume Examples & Samples

Construction Manager Resume Examples & Samples

Construction Manager Resume Examples & Samples

Construction Manager Resume Examples & Samples

Construction Manager Resume Examples & Samples

Construction Manager Resume Examples & Samples

Construction Manager Resume Examples & Samples

Construction Manager Resume Examples & Samples

Construction Manager Resume Examples & Samples

Construction Manager Resume Examples & Samples

Construction Manager Resume Examples & Samples

Construction Manager Resume Examples & Samples

Construction Manager Resume Examples & Samples

Construction Manager Resume Examples & Samples

Construction Manager Resume Examples & Samples

Construction Manager Resume Examples & Samples

Construction Manager Resume Examples & Samples

Construction Manager Resume Examples & Samples

Construction Manager Resume Examples & Samples

Construction Manager Resume Examples & Samples

Construction Manager Resume Examples & Samples

Construction Manager Resume Examples & Samples

Construction Manager Resume Examples & Samples

Construction Manager Resume Examples & Samples

Construction Manager Resume Examples & Samples

Construction Manager Resume Examples & Samples

Construction Manager Resume Examples & Samples

Construction Manager Resume Examples & Samples

How to Make
a Resume

50 Best
Resume Tips

200+ Action
Words to Use

Internship
Resume